文档库 最新最全的文档下载
当前位置:文档库 › 购房合同翻译模板

购房合同翻译模板

篇一:购房合同翻译件英文模板

商品房买卖合同

合同编号:(contract number: xxxxxxxxxxxxx) 合同双方当事人:contractual parties:

出卖人:xxxxxxxxxxxx房地产开发有限公司

seller:xxxxxxxxxxxxxreal estate development co., ltd

注册地址:xx县xx街

registered address: xx,xx county

营业执照注册号:xxxxxxxx

registration number of business license: xxxxxxxxx

企业资质证书号:x建房【xxxx】xxx号

enterprise qualification certificate: 【xxxx】 no.xxx

法定代表人:xxx

legal representative:xxx

联系电话:xxxxxxxxx

tel:xxxxxxxx

邮政编码:xxxxxxxxx

postal code: xxxxxxx

受托代理人:邮编:

地址:

authorized agent:postal code:

委托代理机构:

address:

联系电话:

tel:

authorized agency: 注册地址:

registered address: 营业执照注册号:

registration no. of business license:

法定代表人:

联系电话

legal representative: 邮政编码: postal code:

买受人:xxxxx

tel:

buyer:xxxxxxxxxx

本人/法定代表人姓名:xxxx

personal/ legal representative name:xxxxxxxx

国籍:中国

nationality:china

身份证号码:xxxxxxxxxxxxxxxxxx

i.d.card:xxxxxxxxxxxxxxxxxxxxx

地址:xxxxxxxxxxxxxxaddress:xxxxxxxxxxxxx

邮证编码:xxxxxxxxx

postal code:xxxxxxxxxx

联系电话:xxxxxxxxxxxxxxxxx

tel: xxxxxxxxxxxxxxxxxx

受托代理人姓名:地址:

国籍:

authorized agent name: address:

邮政编码:

nationality

联系电话

postal code:

tel:

根据国家和省法律、法规和有关规定,买受人和出卖人在平等、自愿、协商一致的基础上就买卖商品房达成如下协议:

第一条项目建设依据。

article 1 basis for project construction

出卖人以出让方式取得位于xxxxxxxxxxx 编号为xxx的地块的土地使用权,取得《土地使用权证书》。土地使用权证号为x国用(xxxx)第xxxx号。

the seller obtained the use right of the land parcel ocated located by the number of assignment

该地块土地面积为xxxx平方米,规划用途为商住,土地使用权年限自2011 年至2061 年。the area of this land parcel is 2

出卖人经批准,在上述地块上建设商品房,【现定名】xxxxxxxx。建设工程规划许可证号为xxxxxx,施工许可证号为xxxxxx 。

买受人购买的商品房为【现房】【预售商品房】。预售商品房批准机关为 xx县房地产管理所,商品房预售许可证号为xxxxxxx 号。

买受人购买的商品房为【现房】【预售商品房】(以下简称该商品房,其房屋平面图见本合同附件一,房号以附件一上表示为准)。该商品房为本合同第一条规定的项目中的:

第xxxxxxxxx号楼【幢】【座】x 【单元】x【层】xxx号房。

该商品房的用途为住宅,属混合结构结构,层高为x米,建筑层数地上x 层,地下x 层。该商品房合同约定建筑面积共xx 平方米,其中,套内建筑面积平方米,公共部位与公用房屋分摊建筑面积平方米(有关公共部位与公用房屋分摊建筑面积构成说明见附件二)。

2 in details, the indoor floor area is 2, and the sharing floor area for public places and public housing 2 , ( see attachment 2 to this contract for the constitution of the sharing floor area for public places and public housing)

第四条计价方式与价款。

article 4 charging method and price

出卖人与买受人约定按建筑面积计算,该商品房单价为(人民币)每平方米_xxxx_ __元,总金额为(小写)xxxx元整,(大写)xxxxxxxxxxxxxxx整,币种为人民币。

......

第十九条本合同在履行过程中发生的争议,由双方当事人协商解决;协商不成的,按下述第_2_种方式解决:

article 19 the disputes incurred in performing this contract shall be settled by both parties upon negotiation; if the negotiation fails, settle it in second method as follows:

1.提交仲裁委员会仲裁。 2.依法向人民法院起诉。

2. file a lawsuit to people’s court in accordance with law.

第二十条本合同未尽事项,可由双方约定后签订补充协议(见附件四)。

article 20 in case of unmentioned matters by this contract, both parties shall make agreements and conclude supplementary agreement ( attachment 4)

第二十一条合同附件与本合同具有同等法律效力。本合同及其附件内,空格部分填写的文字与印刷文字具有同等效力。

article 21 each attachment to this contract has the same legal force with thiscontract. in this contract and the attachments thereof, the handwriting content in blank lines has the same legal force with the printing text.

第二十二条本合同连同附件共__xx_页,一式 x 份,具有同等法律效力,合同持有情况如下:出卖人_ x 份,买受人_ x 份,房管所备案x份,抵押x份,银行按揭x份

legal force. the detailed situation is as follows:

the seller copy, the buyer copy, housing administration 第二十三条本合同自双方签订之日起生效。

article 23 this contract takes effect upon date of conclusion by both parties.

第二十四条商品房预售的,自本合同生效之日起30天内,由出卖人向 xx县房地产管理所申请登记备案。

upon the effectiveness of this contract.

出卖人(签章): xxxxxxxxxxxxx房地产有限公司买受人(签章):xxx

seal of the seller: xxxxxxxxxxx real estate development co., ltd signature or seal of the buyer: xxxxxxx

【法定代表人】:xxxxxxx 【法定代表人】:xxxxxx

【委托代理人】:【委托代理人】:(签章) xxx房地产管理所商品房备案专用章(签章)

legal representative: xxxxxxxxxxxx authorized agent:

legal representative:xxxxxx authorized agent:

xx年 xx 月 xx 日xxx年 x月 x 日

date :xxxxxxxxxxxxxx

date: xxxxxxxxxx篇二:房屋买卖合同及其英文翻译

房屋买卖合同书

出卖人:江苏富源房地产开发有限公司

买受人:身份证号:

根据《中华人民共和国合同法》及其他有关法律、法规之规定,买受人和出卖人在平等、自愿、协商一致的基础上就买卖房屋达成如下协议:

第一条买受人所购房屋的基本情况

买受人购买的房屋(以下简称该房屋,其房屋平面图见本合同附件一,房号以附件一上表示为准) ,1号楼15层3号房。

该房屋阳台是非封闭式。

该房屋建筑面积共平方米,其中,公共部位与公用房屋分摊建筑面积米。

第二条计价方式与价款

出卖人与买受人约定按下述第1种方式计算该房屋价款:

按建筑面积计算,该房屋单价为(人民币)每平方米7566元,总金额( 人民币) 捌拾肆万柒千叁百玖拾元整。

第三条付款方式及期限买受人按下列第 1种方式按期付款。

1.一次性付款。买受方在签订购房合同后2日内向出卖方一次性支付房款,¥847,390.00

元,大写:捌拾肆万柒千叁百玖拾元整。

2.分期付款。买受方签订购房合同后与月日前向出卖方预交房价费的%,¥大写元整。剩余房价款待买受方房屋钥匙到时补齐。

3.其他方式。

买受人逾期付款的违约责任

买受人如未按本合同规定的时间付款,按下列第

1.按逾期时间,分别处理(不作累加)

(1)逾期在30日之内,自本合同规定的应付款期限之第二天起至实际全额支付应付款之日止,买受人按日向出卖人支付逾期应付款万分之二十的违约金,合同继续履行;

(2)逾期超过30日后,出卖人有权解除合同。出卖人解除合同的,买受人按累计应付款的20%向出卖人支付违约金。买受人愿意继续履行合同的,经出卖人同意,合同继续履行,自本合同规定的应付款期限之第二天起至实际全额支付应付款之日止,买受人按日向出卖人支付逾期应付款万分之二十的违约金。

第四条交付期限

出卖人应当在2009年12月10日前,依照国家和地方人民政府的有关规定,将具备下列第4种条件,并符合本合同约定的房屋交付买受人使用:

1.该房屋经验收合格。

2.该房屋经综合验收合格。

3.该房屋经分期综合验收合格。

4.该房屋取得商品住宅交付使用批准文件。

但如遇下列特殊原因,除双方协商同意解除合同或变更合同外,出卖人可据实予以延期:遭遇不可抗力,且出卖人在发生之日15 日内告知买受人的;

出卖人逾期交房的违约责任:

除本合同第八条规定的特殊情况外,出卖人如未按本合同规定的期限将该房屋交付买受人使用,按下列方式处理;

1.按逾期时间,分别处理(不作累加)

(1)逾期不超过20日,自本合同第八条规定的最后交付期限的第二天起至实际交付之日止,出卖人按日向买受人支付已交付房价款万分之的违约金,合同继续履行;

(2)逾期超过20日后,买受人有权解除合同。买受人解除合同的,出卖人应当自买受人解除合同通知到达之日起天内退还全部已付款,并按买受人累计已付款的20%向买受人支付违约金。买受人要求继续履行行合同的,合同继续履行,自本合同第八条规定的最后交付期限的第二天起至实际交付之日止,出卖人按日向买受人支付已交付房价款万分之二十的违约金。第五条交接

房屋达到交付使用条件后,出卖人应当书面通知买受人办理交付手续。双方进行验收交接时,出卖人应当出示本合同第八条规定的证明文件,并签署房屋交接单。所购房屋为住宅的,出卖人还需提供《住宅质量保证书》和《住宅使用说明书》。出卖人不出示证明文件或出示证明文件不齐全,买受人有权拒绝交接,由此产生的延期交房责任由出卖人承担。

第六条出卖人保证销售的房屋没有产权纠纷和债权债务纠纷。因出卖人原因,造成该房屋不能办理产权登记或发生债权债务纠纷的,由出卖人承担全部责任。

第七条产权登记

出卖人应当在房屋交付使用后20日内,将办理权属登记需由出卖人提供的资料报产权登记机关备案。如因出卖的责任,买受人不能在规定期限内取得房地产权属证书的,双方同意按下列第项处理;

1.买受人退房,出卖人在买受人提出退房要求之日起日内将买受人已付房价款退还给买受人,并按已付房价款的

2.买受人不退房,出卖人按已付房价款的向买受人支付违约金。

第八条买受人的房屋仅作住宅使用,买受人使用期间不得擅自改变该房屋的建筑主体结构、承重结构和用途。除本合同及其附件另有规定者外,买受人在使用期间有权与其他权利人共同享用与该房屋有关联的公共部位和设施,并按占地和公共部位与公用房屋分摊面积承担义务。

出卖人不得擅自改变与该房屋有关联的公共部位和设施的使用性质。

第九条本合同在履行过程中发生的争议,由双方当事人协商解决;协商不成的,按下述第种方式解决:

1.提交仲裁委员会仲裁。

2.依法向人民法院起诉。

第十条本合同未尽事项,可由双方约定后签订补充协议。

第十一条合同附件与本合同具有同等法律效力。本合同及其附件内,空格部分填写的文字与印刷文字具有同等效力。

第十二条本合同连同附件共页,一式二份,具有同等法律效力,合同持有的情况如下:

出卖人一份,买受人一份。

第十三条本合同自双方签订之日起生效。自本合同生效之日起30天内,由出卖人申请登记备案。

出卖人(签章):江苏富源房地产开发有限公司买受人(签章):

法定代表人:

委托代理人:

联系电话:联系电话:

签于年月日签于年月日篇三:英文版购房合同

contract

vendee:

[ myself]【legal representative】 name:

【id card】【 passport】【business license registration number】【】address:zip code: telephone:

【entrusted agent】【】name: nationality: address:zip code: telephone:according to the《peoples republic of china law of contract》, 《peoples

republic of china city real estate control law》 and other relevant laws

and regulations,the vendee and seller should be base on the equality, voluntarily, consults unanimously foundation to reach the following

article 1project construction basis 【contract number for granting of land-use right 】【document number for

allowing and authorizing of land-use right】【document number for transferring above land parcel, 【present name】,【 temporary name 】, the builder’s permit licence number is

article 2residential basis.

advance】,the total

total area is ,the buyer has already purchased

of presale fund specified account is ,

.

room number is bases on the appendix 1 details )which stipulated in the first article of the contract is:

【tents】()specific house number is

_㎡,there are ㎡,__㎡.

the balcony of this apartment is [sealed] or [not sealed].

as [stipulated on contract]

or [property registration]. the usable area ㎡, with public area to be

( refer to the attachment2 for public area to be shared

construction explanation )

article 4 valuation mode & price /㎡according to the usable area, the unit price of this apartment /㎡according to the usable area, the unit price of this apartment /㎡should subject to the related regulation of [opinions on the

from yantai residential administration bureau. the buyer transfer the capital to the designated bank directly, the seller cannot get the presale capital directly.

5.

article 5 area confirmation& difference treatment

according to the valuation mode which interested parties choosed, this article stipulates the area confirmation&difference treatment according to [building area][usable area]( hereinafter called area for short).

this article does not apply to the interested parties which charge the apartment by set.

the property registration area will be subject to the surveying and drawing report issued by qualified mapping unit designated by residential

administration dept.

for any differences in contracted area& registration area, the registration area will be taken as the standard.

after the apartment is transferred to the buyer, for any differences in contracted area& registration area, which was not stipulated in the contract, both parties will agree to manage according to the following principle: charge as per actual area, return the overcharge and demand payment of the shortage on the

prepaid capital.

1.if the absolute value difference is within 3%( include 3%), the charge will be according to actual amount.

1.if the absolute value difference is exceeds 3%( include 3%), the buyer has rights to cancel the order.

for the buyer who cancel the order, the seller must return the money to buyer within 30days after buyer make the order cancel application, and pay the

for the buyer who will not cancel the order, if the registration areas is within3%(including 3%) bigger than contracted area, the exceeded amount shoud be supplemented by the buyer; for the case which is more than 3%, the exceeded amount should be born by the seller, the property rights belongs to the buyer. if the registration areas is smaller than contracted area, the area ratio is within 3%((including 3%), the exceeded amount must be returned to the buyer; the amount which are more than 3% must be doubled and return to the buyer. this article is not applicable.

area tolerance ratio=( registration areas- contracted area)/ contracted

areax100%. this article is not applicable.

of contract.

article6 payment& deadline

nd1. full payment

2. installment payment

3.others

article7 the breach of contract responsibility for overdue payment

if the buyer cannot effect the payment in the stipulated time, he or she will be ndnd due payment date to the

actual payment date, the buyer should pay to the fine

according to the overdue date, the contract will continue to be performed.

2) if the overdue date is exceeds__days, the buyer has the rights to terminate the contract. if so, the buyer should pay to the fine

according to the overdue date, the contract will continue to be performed, from the 2nd due payment date to the actual payment date, the buyer should pay to

to the overdue date.

the overdue payment in this article refers to the balance between 6th article due payment and acutal effected payment; for installment payment, it should

be decided by the balance between due istallment and actual payment.

article8 handover deadline

5. _____________________________________________________________________-

but in case of the following exceptional reasons, except for both parties agree the termination or alternation of contract, the seller can prolong the deadline as per actual fact.

1. encountered with majeure, and seller informed the buyer within 30 days after the majeure occurs;

2. the seller caused the project cannot be finished on time because of non-controllable reasons.

3. if the delay is because of the above cases, this article is also applicable. article9 responsibility of delay in handover apartment

except for the special cases stipulated in article8, if the seller cannot handover the apartment to buyer in the stipulated schedule in this contract, the buyer should be treated in the following 1st&2nd mode:

1. according to the overdue time, the seller should be treated separately( not be accumulated)

1) for overdue date less days, from the 2nd day of deadline

stipulated in article8 to the payment day, the buyer should pay _____% default fine of the already effected payment, this contract will be performed continuously. 2) for overdue date more days, the buyer can terminate the

contract. in this case, the seller should return all the payment within 30days after the date of termination, and pay __2___% default fine of the already effected payment. if the buyer request continuously perform the contract, this contract will be performed continuously. from the 2nd day of deadline stipulated in article8 to the payment day, the rates in 1) )of the already effected payment

2._____________________________________________________________________ ___________________________________________________________

正式购房合同(标准版)模板

The obligee in the contract can accomplish the goal in a certain period by discussing the agreed rights and responsibilities. 甲方:___________________ 乙方:___________________ 时间:___________________ 正式购房合同(标准版)

编号:FS-DY-28593 正式购房合同(标准版) 出卖人(甲方): 买受人(乙方): 根据中华人民共和国有关法律、法规和本市有关规定,甲、乙双方遵循自愿、公平和诚实信用的原则,经协商一致订立本合同,以资共同遵守。 第一条甲乙双方【未通过经纪机构居间介绍】【通过公司居间介绍(房地产执业经纪人:,经纪人执业证书号:】,由乙方受让甲方自有房屋及该房屋占用范围内的土地使用权(以下简称房地产),房地产具体状况如下: (一)甲方依法取得的房地产权证号为:, (二)房地产座落:(部位:)。房屋类型:;结构:; (三)房屋建筑面积:平方米,另有地下附属面积平方米。该房屋占用范围内的土地使用权【面积】【分摊面积】:平方米。

(四)房屋平面图和房地产四至范围(附件一); (五)该房屋占用范围内的土地所有权为【国有】【集体所有】;国有土地使用权以【出让】【划拨】【转让】方式获得。 (六)随房屋同时转让的设备(非房屋附属设备)及装饰情况见附件二。 (七)甲方转让房地产的相关关系(包括抵押、相邻、租赁等其他关系)见附件五。 甲方保证已如实陈述房地产权属状况、设备、装饰情况和相关关系,乙方对甲方上述转让的房地产具体状况充分了解,自愿买受该房地产。 第二条甲、乙双方经协商一致,同意上述房地产转让价款为(人民币)为元,(大写):元整。 乙方的付款方式和付款期限由甲、乙双方在付款协议(附件三)中约定明确。乙方交付房价款后,甲方应开具符合税务规定的收款凭证。 第三条甲方转让房地产时,土地使用权按下列第款办理。 (一)该房屋占用的国有土地使用权的使用年限从年月日起至年月日止。甲方将上述房地产转让给乙方后,出让合同

房产证翻译中英文对照

X京房权证朝字号:1203587 X Beijing House Property Right Certificate Chao Zi 1203587

房屋所有权人赵四 Owner of the house Zhao Si 共有情况共同共有 Co-ownership Circumstance Joint possession 房屋坐落朝阳区和平街十区19号楼3层2单元306 Location Room 306, Unit 2, Floor 3, Apt. 19, Zone 10 Heping Streest, Chaoyang District 登记时间2013-01-16 Date of registration January 16, 2013 房屋性质商品房 Housing property Commercial residential building 住宅 规划用途 Residence 房屋状况建筑面积套内建筑面积 总层数其他 Building Building area Building area in the suite Total floors Others Condition (就)(就)

附记 Remarks 共有人房屋所有权共有份额 赵四X京房权朝字第1203587号共同共有 王五X京房权朝字第1203587号共同共有 Co-owner HouseProperty Right Certificate No. Share of co-ownership Zhao Si X Beijing House Property Right Certificate No. 1203587 Joint possession

购房合同范本样本大全

合同模板Contract template 购房合同范本样本大全A4大小 \ 自由编辑 \ 最新最热 \ 标准模板

购房合同范本样本大全 我们以标准购房合同为范本,将其中需要重点注意、容易产生争议的部分作了详尽的注解,希望对您签订购房合同有所帮助。 合同中有蓝色下划线部分可点击察看详解 合同中有红色下划线部分为核心内容,请务必详查商品房买卖合同范本1、本合同文本为示范文本,也可以作为签约使用文本。签约之前,买受人应当仔细阅读本合同内容,对合同条款及专业用词理解不一致的,可向当地房地产开发主管部门咨询。 2、本合同所称商品房是指由房地产开发企业开发建设并出售的房屋。 3、为体现合同双方的自愿原则,本合同文本中相关条款后都有空白行,供双方自行约定货补充约定。双方当事人可以对文本条款的内容进行修改、增补或删减。合同签订生效后,未被修改的文本印刷文字视为双方同意内容。 4、本合同中涉及到的选择、填写内容以手写项为优先。 5、对合同文本【】中选择内容、空格部位填写及其他需要删除或添加的内容,双方应当协商确定。【】中选择内容,以划√方式选定;对于实际情况未发生或买卖双方不作约定时,应在空格部位打×,以示删除。 6、在签订合同前,出卖人应当向买受人出示应当由出卖人提供的有关证书、证明文件。 合同双方当事人: 出卖人:_________________ 注册地址:_________________ 营业执照注册号: 企业资质证书号: 法定代表人:_______联系电话:_____ 邮政编码:______ 委托代理人:__________ 邮政编码:________ 注册地址:______________ 营业执照注册号:_____________ 【本人】【法定代表人】姓名:_____国籍____ 【身份证】【护照】【营业执照注册号】_____ 地址:_________ 【委托代理人】姓名:_____国籍:_______

购房合同样本标准版

购房合同样本标准版 (合同编号:) 合同双方当事人: 出卖人:_________________________________________________________注册地址:_______________________________________________________营业执照注册号:_________________________________________________企业资质证书号:_________________________________________________法定代表人:____________________联系电话:_______________________邮政编码:_______________________________________________________委托代理人:____________________地址:__________________________邮政编码:____________________联系电话:________________________委托代理机构:__________________________________________________注册地址:______________________________________________________营业执照注册号:________________________________________________法定代表人:____________________联系电话:______________________邮政编码:______________________________________________________买受人:________________________________________________________【本人】【法定代表人】姓名:__________________国籍______________【身份证】【护照】【营业执照注册号】【】_______________________地址:__________________________________________________________邮政编码:______________________联系电话:______________________【委托代理人】【】姓名:____________________国籍:_____________地址:__________________________________________________________邮政编码:______________________电话:__________________________

开发商购房合同范本(完整版)

合同编号:YT-FS-4106-46 开发商购房合同范本(完 整版) Clarify Each Clause Under The Cooperation Framework, And Formulate It According To The Agreement Reached By The Parties Through Consensus, Which Is Legally Binding On The Parties. 互惠互利共同繁荣 Mutual Benefit And Common Prosperity

开发商购房合同范本(完整版) 备注:该合同书文本主要阐明合作框架下每个条款,并根据当事人一致协商达成协议,同时也明确各方的权利和义务,对当事人具有法律约束力而制定。文档可根据实际情况进行修改和使用。 开发商购房合同范本 甲方(卖方): ( 代签) 乙方(买方): 依据《中华人民共和国合同法》及相关法律法规之规定,买卖双方本着平等、自愿、协商一致的原则,就房屋买卖有关事项,达成如下协议: 第一条:房屋基本情况 乙方购买甲方合法拥有的坐落于,建筑面积平方米,地下室平方米的房产一套,由于房主已故,该房产由房主6子女共同继承,经房主6子女协商一致同意授权并委托房主三子李根明全权代表负责房屋的一切事务及承担房屋买卖协议中的所有责任和义务,以下条款中所有甲方承担的责任和义务均有李根明履

行。 第二条:付款方式 双方议定上述房产出售价格为万元整(大写万元整)。协议签订后乙方支付甲方合同保证定金万元整,剩余房款乙方须在年月日 第三条:房屋过户 1、因本合同签定时该房产为下花园煤矿沉陷区拆迁房,暂无房产证,所以甲乙双方都不具备过户条件,等过户条件成熟时,甲方应协助乙方办理房屋产权手续,因甲乙任何一方不配合所造成的损失,由责任方赔偿守约方。经甲乙双方协商一致同意办理张家口市下花园区中学西街盛源小区9号楼1单元2楼2号房产过户乙方时所需缴纳的税费、手续费及各种费用均由乙方承担。 2、本合同签订后,甲方对张家口市下花园盛源小区9号楼1单元2楼2号的房屋使用、收益、出租、担保、抵押、买卖、占有等权利一并转让给乙方。 3、本合同签订后,甲方保证乙方享有同甲方相同

正规购房合同书样本(示范合同)

正规购房合同书样本(示范合 同) Contracts concluded in accordance with the law have legal effect and regulate the behavior of the parties to the contract ( 合同范本 ) 甲方:______________________ 乙方:______________________ 日期:_______年_____月_____日 编号:MZ-HT-021645

正规购房合同书样本(示范合同) 篇一:正规购房合同范本 甲方(售房人): 乙方(买房人): 见证人: 第一条 甲方自愿将其房屋出售给乙方,乙方也已充分了解该房屋具体状况,并自愿买受该房屋。该房屋具体状况如下: (一)座落于,建筑面积为平方米(此面积不含地下室面积); (二)出售房屋的所有权证证号为 ; (三)房屋平面图及其四至见房产证; 该房屋占用范围内的土地使用权随该房屋一并转让。 该房屋的相关权益随该房屋一并转让。

第二条 甲方保证已如实陈述上述房屋权属状况和其他具体状况,保证该房屋不受他人合法追索。 第三条 乙方在前付给甲方定金(人民币),(大写)元,(小写)元。 上述定金在乙方最后一次付款时充抵房款在时由甲方退还乙方。 第四条 该房屋协议价格为(人民币)(大写) 元,(小写) 元。 房价款的支付方式和支付时间为: 第五条 1、甲、乙双方定于时正式交付该房屋;甲方应在正式交付房屋前腾空该房屋。 2、双方定于前向有关部门申请办理相关附属设施和相关权益的更名手续。 4、甲方未按规定履行以上义务的,则按下列约定承担违约责任:

购房合同翻译模板

篇一:购房合同翻译件英文模板 商品房买卖合同 合同编号:(contract number: xxxxxxxxxxxxx) 合同双方当事人:contractual parties: 出卖人:xxxxxxxxxxxx房地产开发有限公司 seller:xxxxxxxxxxxxxreal estate development co., ltd 注册地址:xx县xx街 registered address: xx,xx county 营业执照注册号:xxxxxxxx registration number of business license: xxxxxxxxx 企业资质证书号:x建房【xxxx】xxx号 enterprise qualification certificate: 【xxxx】 no.xxx 法定代表人:xxx legal representative:xxx 联系电话:xxxxxxxxx tel:xxxxxxxx 邮政编码:xxxxxxxxx postal code: xxxxxxx 受托代理人:邮编: 地址: authorized agent:postal code: 委托代理机构: address: 联系电话: tel:

authorized agency: 注册地址: registered address: 营业执照注册号: registration no. of business license: 法定代表人: 联系电话 legal representative: 邮政编码: postal code: 买受人:xxxxx tel: buyer:xxxxxxxxxx 本人/法定代表人姓名:xxxx personal/ legal representative name:xxxxxxxx 国籍:中国 nationality:china 身份证号码:xxxxxxxxxxxxxxxxxx i.d.card:xxxxxxxxxxxxxxxxxxxxx 地址:xxxxxxxxxxxxxxaddress:xxxxxxxxxxxxx 邮证编码:xxxxxxxxx postal code:xxxxxxxxxx 联系电话:xxxxxxxxxxxxxxxxx tel: xxxxxxxxxxxxxxxxxx 受托代理人姓名:地址: 国籍: authorized agent name: address: 邮政编码: nationality

购房合同书样本

范文一: 合同双方当事人: 出卖人:_________________________________ 注册地址:_________________________________ 营业执照注册号: 企业资质证书号: 法定代表人:_____________ 联系电话:__________ 邮政编码:___________ 委托代理人:__________________ 邮政编码:_______________ 注册地址:___________________________ 营业执照注册号:_________________________ 【本人】【法定代表人】姓名:________ 国籍 _______ 【身份证】【护照】【营业执照注册号】________ 地址:_________________ 【委托代理人】姓名:_______ 国籍:______________ 根据《中华人民共和国合同法》、《中华人民共和国城市房地产管理法》及其他有关法律、法规之规定,买受人和出卖人在平等、自愿、协商一致的基础上就买卖商品房达成如下协议:第一条项目建设依据 出卖人以____________________ 方式取得位于______________________ 、编号为 _______ _____________ 的地块的土地使用权。 第二条商品房销售依据 【土地使用权出让合同号】【土地使用权划拨批准文件号】【划拨土地使用权转让批准文件号】为_________________ 。 该地块土地面积为_____________________ ,规划用途为_____________________ ,土地使 用年限自___________ 年________ 月__________ 日至 ____ 年—月_______ 日。 出卖人经批准,在上述地块上建设商品房,【现定名】【暂定名】 ____________________ 。 建设工程规划许可证号为_____________________ ,施工许可证号为 __________ 。 第二条商品房销售依据 买受人购买的商品房为【现房】【预售商品房】。预售商品房批准机关为_________________ ___ ,商品房预售许可证号为___________________ 。 第三条买受人所购商品房的基本情况买受人购买的商品房(以下简称该商品房,其房屋平面图见本合同附件一,房号以附件一上表示为准)为本合同第一条规定的项目中的: 第_____________________ 【幢】【座】____________________ 【单元】【层】_________ ___________ 号房。 该商品房的用途为_____________________ ,属 _____________________ 结构,层高为— ----------------- ? 建筑层数地上____________________ 层,地下______________________ 。 该商品房阳台是【封闭式】【非封闭式】。 第六条买受人所购商品房的基本情况 该商品房【合同约定】【产权登记】建筑面积共_____________________ 平方米,其中,套内 建筑面积____________________ 平方米,公共部位与公用房屋分摊建筑面积____________ _________ 平方米(有关公共部位与公用房屋分摊建筑面积构成说明见附件二)。 第四条计价方式与价款

合同范本之购房合同英文翻译

购房合同英文翻译 【篇一:商品房买卖合同中英文翻译模板】 serial no. :327338 commercial housing sales contract supervised and made by beijing municipal bureau of state land and resources and house management instructions of commercial housing sales contract 1. the contract is a sample contract; which is made together by beijing construction committee and beijing administration for industry and commerce. 2. the commercial house in the contract refers to the house built and sold by the enterprise of real estate development. 3. party involved should sign the contract based on willingness, justice, honesty and reputation. any party cannot give the law to the counterpart. both parties can carry out amendment, supplement and deletion to clauses in the contract. after the contract taking effect, as to the printed words without alteration, it can be considered that both parties agree with the contents. 4. as for the selected options, handwriting is preferential. 5. as to [ ] options, blank filling and other contents needed to be deleted or added in the contract, both parties should make a decision by negotiation. [ ] use √ to choose options; with regard to the practical conditions not happened 6. before signing, vendor should show license of presale of commercial housing and other related certificates and documentary evidence to buyer. 7. the contract articles are explained by ministry of construction of the p.r.c.

2016最新上海房产证英文翻译模板

Shanghai Certificate of Real Estate Ownership Hu Real Estate Certificate xxx zi ( 2016 ) No. 123456 *123456789012* Date of Issue: 05/31/2016 In accordance with the Property Low of the People's Republic of China, the Law of Land Administration of the People's Republic of China, the Law of Urban Real Estate Administration of the People's Republic of China, Shanghai Regulations for Real Estate Registration and other relevant laws and regulations, to protect the legal rights and interests of the owner of land-use rights and the house property, registration is hereby granted and this certificate is hereby given to such owner for the land, house and other appurtenances listed in this his/her registration application after due examination and verification. This certificate is the proof of title to the real estate on the State-owned land lot. Shanghai Housing Security & Administration Bureau Shanghai Planning, Land &Resource Administration Bureau (Seal) (Seal)

购房合同备案查询四大注意事项

篇一:签购房合同八大注意事项 签购房合同注意事项 一查证 1.最主要的应该看两证,一个是国有土地使用证,一个是预售许可证。一定要看原件。要看清楚您所预购的房屋是不是在预售范围之内,以确保将来顺利的办理产权证。商品房预售,开放经营企业应当与消费者签订商品房预售合同,预售人应当在签约之日起三十日内持商品房预售合同向县级以上房地产管理部门和土地管理部门办理登记备案手续。确保将来顺利的办理产权证。 2.必须要求承诺办理产权证的时间。明确房产证办理的具体时间以及无房产证、迟办房产证的违约责任。出卖人应当协助买受人于房屋交付之日起或合同签订之日起90日内,办理产权登记手续。(第一阶段,开发企业应当在交付使用后60日内将需要由其提供的办理房屋权属登记的资料报送产权登记机关;第二阶段的30日里,由买受人办理产权登记手续) 3.应注意新建商品房应取得《住宅交付使用许可证》后方可交付使用,无《住宅交付使用许可证》的,公安部门不予办理入户手续。 4.房地产开发企业在商品住宅交付使用时,应当向消费者提供《住宅质量保证书》和《住宅使用说明书》,并按《住宅质量保证书》的约定承担保修责任。确保将来顺利的办理产权证。二房屋面积的条款 1.建筑面积、套内面积、使用面积和公摊的面积(自己分摊的公用面积)及其测量方法要明晰。具体做法:a,应在条款中写明建筑面积,建筑面积中含公用面积的组成部分及具体平米数、使用面积平米数、建筑面积与使用面积的比例。 b,公摊面积:和开发商约定清楚,不仅要有一个笼统的公摊面积的数字,而且要约定公摊的是哪一部分,要确定公摊的位臵。现在有很多赠与这个,赠与那个,实际上有的时候是公用的面积。 c,其他:所购楼房的楼号、房号、单元在整幢楼中的位臵示意图、单元的平面图也应在合同中写明或作为附件。另外房子宏观规划(主要是外部环境)要详细约定。 面积差异的处理方式:一种是双方自行约定,约定使用面积不能大于1%,或者0.5%;另一种,约定面积误差比绝对值在3%以内的据实结算房款,面积误差比绝对值超过3%,开发商必须承担违约责任,同时允许购房者退房。某些开发企业将这一条规定在合同中直接格式化为“多退少补、据实结算”,此点必须注意不接受,约定清楚。 2.房屋质量的条款 要详细地把质量要求写进合同。如:卧室、厨房、卫生间的装修标准、等级,建材配备清单、等级,屋内设备清单,水、电、气、管线通畅,门、窗、家具瑕疵,房屋抗震等级等。同时,合同中还可以规定房屋的保质期、附属设备保质期等。(下水道堵塞、墙面渗水、屋顶漏雨、墙体起鼓等等问题) 注意:涉及装饰、设备标准承诺和基础设施、公共配套建筑正常运行的承诺时,合同要求双方对有关承诺的违约责任作出处理约定。避免笼统地写上“由出卖人继续完善”或是“由买卖双方协商解决”,或干脆空白不填。另外要注意楼盘小区内的规划及配套是否与广告说明相符。如户型、绿化、相关配套设施、开发商对小区的承诺等,可以以“附页”或“附条件合同”的形式签订。 下列情况,购房人因为房屋质量问题,有权要求解除合同并要求赔偿损失:房屋主体结构质量不合格,不能交付使用;房屋交付使用后,房屋主体结构质量经检验确属不合格;因房屋质量问题严重影响正常居住使用。交付使用的房屋存在质量问题,在保修期内,出卖人应当承担修复责任;出卖人拒绝修复或者在合理期限内拖延修复的,买受人可以自行或者委托他人修复。修复费用及修复期间造成的其他损失由出卖人承担。

房产证英文翻译模板-重庆

Housing Ownership Certificate of Chongqing City Page1: Made and supervised by the Construction Ministry of Chongqing City No.XXX Page2: XXX House Property Ownership Certificate No. XXX According to the “Constitution of the People’s Republic of China”、the “Law of the People's Republic of China relating to Administration of Urban Real Estate”and “Land Housing Authority registration ordinance of Chongqing City”to protect the legal interests of the house owner who applied to register, the real estate listed here was proved to be authentic. Hereby is the certificate. Issued by: Chongqing Real Estate Management Bureau (Seal) Issued License Office Chapter: Chongqing Real Estate Management Bureau (Seal) Date of issuing license:XXX

购房合同翻译件英文模板

商品房买卖合同Commodity house purchase and sale contract (Contract Number: xxxxxxxxxxxxx)合同编号:合同双方当事人:Contractual Parties: 出卖人:xxxxxxxxxxxx房地产开发 有限公司Seller:xxxxxxxxxxxxxreal estate development Co., LTD 注册地址:xx县xx街Registered a ddress: xx,xx County 营业执照注册号:xxxxxxxx Registration n umber of Business l icense: xxxxxxxxx 企业资质证书号:x建房【xxxx】xxx号Enterprise qualification certificate: 【xxxx】 No.xxx 法定代表人:xxx Legal representative:xxx 联系电话:xxxxxxxxx Tel:xxxxxxxx 邮政编码:xxxxxxxxx Postal code: xxxxxxx 受托代理人:地址: Authorized agent: Address: 邮编:联系电话: Postal code: Tel: 委托代理机构: Authorized agency: 注册地址:Registered a ddress: 营业执照注册号:Registration No. of Business License: 法定代表人: 联系电话 Legal Representative: Tel: 邮政编码:Postal code: 买受人:xxxxx Buyer:xxxxxxxxxx 本人/法定代表人姓名:xxxx Personal/ Legal representative Name:xxxxxxxx 国籍:中国Nationality:China 身份证号码:xxxxxxxxxxxxxxxxxx

售楼部购房合同范本(标准版)

编号:FS-HT-05018 售楼部购房合同(标准版) Model of purchase contract of sales department 甲方:________________________ 乙方:________________________ 签订日期:_____年____月____日 编订:FoonShion设计

售楼部购房合同(标准版) 出卖方(简称甲方)_______ 买受方(简称乙方)_______ 甲、乙双方本着平等、自愿的原则,同意就下列事项订立本《商品房认购协议书》,以资甲、乙双方共同遵守: 一、乙方认购甲方开发的位于_________住宅小区的下列物业: 1.商品住宅:______号楼______座______号,建筑面积______平方米。 2.商铺:______号楼______号,建筑面积______平方米。 3.车位(库)______号,建筑面积______平方米。 二、上述房屋的价格 1.商品住宅:人民币每平方米______元,合计人民

币:______元。优惠价为______,实际成交价格为人民币:______元。(买受人如选择公积金按揭贷款方式,商品住宅的优惠价为______元,成交价格为______元) 2.商铺:人民币每平方米______元,合计人民币:______元。优惠价为______,实际成交价格为人民币:______元。 3.车位:人民币每间(位)______元,合计人民币:______元。 以上______项合计人民币:______元(大写)______佰______拾______万______仟______佰______拾______元整。 三、乙方应于签订本协议书的同时向甲方交付签约定金人民币______万元整(其中住宅定金______万元,商铺定金______万元,车位定金______万元)甲方另开《收款收据》。 四、乙方选择的付款方式 1.一次性付款:乙方须在签订《商品房买卖合同》的同时,一次性付清购房款(已付的定金抵作价款)

购房合同翻译件英文 模板

商品房买卖合同 Commodity house purchase and sale contract 合同编号:(Contract Number: xxxxxxxxxxxxx) 合同双方当事人: Contractual Parties: 出卖人:xxxxxxxxxxxx房地产开发有限公司 Seller:xxxxxxxxxxxxxreal estate development Co., LTD 注册地址:xx县xx街 Registered address: xx,xx County 营业执照注册号:xxxxxxxx Registration number of Business license: xxxxxxxxx 企业资质证书号:x建房【xxxx】xxx号 Enterprise qualification certificate: 【xxxx】No.xxx 法定代表人:xxx Legal representative:xxx 联系电话:xxxxxxxxx Tel:xxxxxxxx 邮政编码:xxxxxxxxx Postal code: xxxxxxx 受托代理人:地址: Authorized agent: Address: 邮编:联系电话: Postal code: Tel: 委托代理机构: Authorized agency: 注册地址: Registered address: 营业执照注册号: Registration No. of Business License: 法定代表人:联系电话 Legal Representative: Tel: 邮政编码: Postal code: 买受人:xxxxx Buyer:xxxxxxxxxx 本人/法定代表人姓名:xxxx Personal/ Legal representative Name:xxxxxxxx 国籍:中国 Nationality:China 身份证号码:xxxxxxxxxxxxxxxxxx I.D.Card:xxxxxxxxxxxxxxxxxxxxx 地址:xxxxxxxxxxxxxx

购房合同范本经典版

合同编号:2021-xx-xx 合同/协议(模板) 合同名称: 甲方: 乙方: 签订时间: 签订地点:

购房合同范本经典版 甲方:__________(出卖人) 法定代表人:__________ 地址:__________ 邮编:__________ 电话:__________ 传真:__________ 乙方:__________(买受人) 地址:__________ 邮编:__________ 电话:__________ 身份证号码:__________ 为了保护商品房交易双方的合法权益,甲、乙双方经友好协商,就乙方认购甲方开发建设的商品房一事达成如下协议:__________ 一、房屋基本情况:__________乙方预定甲方开发建设的位于_____市_____区县_____路_____号楼盘:__________ 号楼_____单元_____号房屋,建筑面积__________平方米,其中套内建筑面积__________平方米,公用建筑分摊面积为_______________平方米。房屋单价_____元(美元)/平方米,总房款为(小写)_______________元(美元),(大写)____________________元(美元)。户型为____________________。

二、认购期间:甲方承诺为乙方所预定房屋保留天(自_____年_____月_____日至_____年_____月_____日)。 三、定金:本协议签订时,乙方向甲方支付定金人民币(小写) _______________元(美元),(大写) _______________元(美元)。乙方须在上述房号保留期限内,携本协议到甲方售楼处,与甲方协商签订《商品房买卖(预售)合同》有关事宜。上述定金在甲、乙双方签订《商品房买卖(预售)合同》时,由甲方退还乙方或抵作该房屋的购房价款。 四、付款方式:乙方同意选择下列_____种付款方式,在与甲方签订《商品房买卖(预售)合同》后向甲方支付购房价款。 1、一次性付款 2、分期付款:于签约当日付_____%,剩余房款在_____日内分_____次付清; 3、个人住房抵押贷款:__________于签约当日付清房屋总价_____%的首付款。 五、证明文件:__________甲方应向乙方出示下列证件及其附属材料,甲方保证以下资格认证文件真实无瑕疵。 1、企业法人营业执照证号:__________ 2、政府立项证明证号:__________ 3、房地产开发企业资质证书证号:__________ 4、国有土地使用权证书证号:__________ 5、建设工程规划许可证(包括附图) 证号:__________

样本-房产证英文翻译

Formulated by the Ministry of Construction of the People’s Republic of China House construction registration number: Ning House Proprietorship Certificate Construction Xuan Transfer No. According to the stipulations in Constitution of the People’s Republic of China and Real Estate Administration Law in Cities of the People’s Republic of China, this certificate is hereby issued for the purpose of protecting the legal rights and interests of house proprietors with the real estate listed in this certificate and applied for registration by the proprietors being checked and proved to be true. Certificate Issued by (seal): Real Estate Administration Bureau of Nanjing City (seal)

Filled and issued by (seal): Date of filling and issuing: October 10, 2003

购房合同样本(官方版)

购房合同样本(官方版) 甲方(卖方): 乙方(买方): 甲、乙双方就房屋买卖事项,经协商一致,达成以下合同条款: 一、甲方自愿将坐落在济南市区路小区号楼单元室(建筑面积平方米,储藏室平方米,产权证号)房地产出卖给乙方,并将与所出卖该房产的相关的土地使用权同时出卖给乙方(附房产证复印件及该房产位置图)。 二、双方议定上述房地产及附属建筑物总价款为人民币大写 ;即人民币小写 . 三、乙方在签订本合同时,支付定金,即小写 . 四、乙方支付定金之日起个月内,向甲方支付首付款(定金从中扣除),首付款之外的款项通过银行住房按揭方式交付(有关期限和程序按照所在按揭银行规定办理)。 五、甲方保证该房产合法、权属清楚、有合法的土地使用权(已交纳土地出让金)。 六、办理房产证手续所产生的有关税费由方承担。 七、乙方支付首付款后,甲方即积极配合乙方办理有关房产过户手续,待房产过户到乙方名下之时,乙方应向甲方付清全部房款余额。 八、甲方应在前将该房产交付乙方;届时该房产应无任何担保、抵押、房产瑕疵,无人租住、使用;无欠账,如电话费、水电费、物业管理费、取暖费、入网费、有线电视费等。 九、本合同签订后,如一方违反本合同条款,该方应向对方支付元的违约金;一方如不能按规定交付房产或按规定支付房款,每逾期一日,应向对方支付五十元罚金,逾期30日视为毁约;如因政府及银行规定,本合同涉及房产手续客观上不能办理过户或银行不能办理按揭导致合同解除,不适用本条款。 十、交付该房产,甲方不得损坏该房产的结构、地面和墙壁及不适移动的物件,并将抽风机一台(型号: ),空调两台(型号: ),热水器(型号: ),浴霸(型号: ),饮

购房合同范文模板新

合同编号: ___________ 购房合同范文模板2020新 甲方: ____________________________________ 乙方: ________________________________________ 20 年月日

甲方(房屋出售方):身份证号码: 地址:联系电话: 乙方(房屋购买方):身份证号码: 地址:联系电话: 按照《中华人民共和国合同法》和其他有关法律、法规,经甲、乙双方协商一致,本着平■等自愿原则,订立本合同。 第一条甲方自愿将其房屋出售给乙方,乙方也已充分了解该房屋具体状况,并自愿买受该房屋。该房屋具体状况如下: (一)座落丁神木县人民路南第一排沙渠小区独院,建筑面积280平方米; (二)该房屋占用范围内的土地使用权随该房屋一并转让。该房屋的相关权益随该房屋一并转让。 第二条乙方在前付给甲方定金人民币(大写)元,(小写)人民币元 上述定金在乙方最后一次付款时充抵房款。甲方收到定金后,中途不得借故中止售房,否则加倍赔偿定金,乙方未能如期签订购房合同、付活房款,则支付给甲方的定金不予退还。 第三条该房屋房价款为人民币(大写)元,(小写)人民币元。 房价款的支付方式和支付时间为: 第四条本契约自甲乙双方签订之日起生效。 第五条本契约一式两份。其中甲方留执一份,乙方留执一份。 甲方(签章):乙方(签章): 签约日期:签约日期:

签合同的注意事项如下(使用时请删除): 一、在签订合同以前,经营者必须认真审查对方的真实身份和履约能力。 二、审查合同公章与签字人的身份,确保合同是有效的。如果对方公章为法人的分支机构公章或内设机构,应要求其提供所届法人机构的授权书。对方在合同上签公章,并不能保证合同是有效的,还必须保证合同的签字人是对方的法定代表人或经法人授权的经办人。 三、签订合同时应当严格审查合同的各项条款,有条件的不妨向专业人员咨询。根据合同诈骗的特点,为了防止对方利用合同条款来弄虚作假,应该严格审查合同各项条款以便使合同权利义务关系规范、明确,便丁履行。 四、约定违约条款。 五、约定争议管辖权条款。 六、明确合同签订地。 七、约定担保条款(视具体情况而定)。

相关文档
相关文档 最新文档