国际商务合同中英文对照
国际商务合同中英文对照
1 Whereas
Whereas: considering that 鉴于，就……而论（法律用语）
例1
Whereas the first Party is willing to employ the second Party and the second Party agrees to act as the first Party’s Engineer in Bamako, it is hereby mutually agreed as follows:
鉴于甲方愿意聘请乙方，乙方同意应聘为甲方在巴马科（工程）的工程师，合同双方特此达成协议如下
例 2
Whereas Party B and Party A have entered into this Contract to install Party A’s air-conditioning equipment, the Parties hereto do hereby agree as follows: Chinese version for reference:
鉴于乙方与甲方订立本合同，安装甲方的空气调节设备，双方同意如下：
2 In Witness Whereof [❤1]
Whereby：In Witness Whereof：作为所协议事项的证据，这个短语常常在合同
”，“以此立（证）据”等；
In Testimony Whereof：以此为证，特立此证；
Whereby: by the agreement; by the following terms and conditions, etc.凭此协议，凭此条款等。
例 1
In Witness Whereof the Parties hereto have caused this Agreement to be executed on the day and year first before written[❤2] in accordance with their respective laws.
本协议书由双方根据各自的法律签订，于上面所签订的日期开始执行，特立此据。
例 2
In Testimony Whereof, we have hereto signed this document on _______(day/month/year).
我方于___年____月____日签署本文，特此证明。
例 3
A sales contract refers to a contract whereby the seller transfers the ownership of an object to the buyer and the buyer pays the price for the object.
买卖合同是出卖人转让标的物的所有权于买受人，买受人支付价款的合同。
3 Know All Men by These Presents;[❤3]
Undersigned; Now Therefore
Undersigned:[❤4]
Now Therefore:[❤5] 特此，因此等。这个短语一般接whereas 之后，引出具体协议事项的常用开头词，并与其后的hereby 连用，译“兹”，“特此”。例 1
Know All Men by these presents that we_(bank’s name)__ having our registered office [❤6] at ______ (hereinafter called “the Bank”) will be bound unto[❤7] _(the Owner’s name)_ (hereinafter called “the Owner”) in sum
“Permanent Works” means the permanent works to be executed[❤20] ” (including Plant) in accordance with the Contract.
Chinese version for reference:
“永久工程”是根据合同将实施的永久工程（包括机械设备）。
例2
Neither the Consultants nor their Sub-consultants nor the Personnel of either of them shall, either directly or indirectly, engage in such business or professional activities in China as conflict with the activities assigned to them under this Contract.
咨询人，分包咨询人或两类人员，均不能直接或间接地在中国从事与本合同所赋予的活动相冲突的商业或职业活动。
例3
“Retention Money[❤21] ” means the aggregate of all monies[❤22] retained by the Employer pursuant to Sub-Clause 60.2(a).
“保留金”是指业主根据第60.2（a）款规定留存的所有款项的总额。
６In Respect of; In Respect Thereof[❤23]
涉及，至于，在……方面，比about, concerning, as regards正式。
例1
Prior to making a claim under the performance security[❤24] , the Employer shall, in every case, notify the Contractor stating the nature of the default in respect of which the claim is to be made.
Chinese version for reference:
根据履约保证，提出索赔之前，在任何情况下，业主应通知承包人，针对提出的索赔说明违约的性质。
例2
The Employer shall indemnify the Contractor against[❤25] all claims, proceedings, damages, costs, charges and expenses in respect of the matters (referred to in the exceptions) defined in Sub-Clause 22.2.
业主应保障承包人免除承担属于第22.2款规定情况下的所有索赔，诉讼，损害，诉讼费，指控费及其他开支。
例3
The Employer shall not be liable to the Contractor for any matter or thing arising out of or in connection with the Contract or execution of the Works, unless the Contractor shall have included a claim in respect thereof in his Final Statement[❤26] and in the Statement at Completion[❤27] referred to in Sub-Clause 60.5.
除非承包人在其最终报表中以及在第60.5款提及的竣工报表中已经包括索赔事宜，对由合同及工程实施引起的或与之有关的任何问题和事件，雇主不应对承包人负有责任。
７In the Event That; In the Event of[❤28]
例1
In the event that the Contract Price or any other terms of the Contract changes after the issuance of the Letter of Credit [❤29] (or letter of
Guarantee[❤30] ) the Owner[❤31] shall arrange for such Letter to be amended accordingly as soon as possible after any such change.
如果在信用证（或保函）开出后，合同总价或合同其他条款发生变化，业主应尽快安排对信用证（或保函）进行相应的修改。
例2
Either Party hereto may terminate this Agreement in the event of the bankruptcy or insolvency of the other party. 本协议任何一方可以在对方破产或资不抵债的情况下终止本协议。
8 Provided that[❤32]
例1
Instructions given by the Engineer shall be in writing, provided that if for any reason the Engineer considers it necessary to give any such instruction orally, the contractor shall comply with such instruction.
Chinese version for reference:
由工程师发出的指令应为书面形式。但规定，如果由于某种原因，工程师认为有必要以口头形式发出指令，承包人应遵照执行。
例2
The Owner may, at its discretion, approve or reject any change proposed by the Contractor, provided that the Owner shall approve any change proposed by the Contractor to ensure the safety of the Works.
Notes: 1) at one’s discretion: freedom to act in accordance with one’s judgment Chinese version for reference:
业主可赞成或拒绝由承包人提出的变更，但应接受承包人提出的保证工程安全方面的变更建议。
9 Be Deemed[❤33]
be believed, be considered. 被认为，法律文件中的正式用语。
例1
Only the Defects Liability[❤34] Certificate referred to in Clause 62, shall be deemed to constitute approval of the Works.
只有第62条规定的缺陷责任书才能视为构成对工程的批准。
10 In Question[❤35]
“在考虑中的或在议论中的”某一问题，可译为“这”或“该”问题。
例1
All prices to be paid by the Buyer under its obligations of the buyback/counter-purchase Contract shall be the world market prices taking into account the other delivery terms[❤36] for the goods in question. Chinese version for reference:
买方根据返销或回购货物合同的义务所支付的价格应为世界市场价格，结合考虑该货物的其他交货条件。
例2
It is common for Tenders to be identified by such a tender reference [❤37] or contract number as shall be added to link the Tender to the Project in question.
通常为了把投标书和有关工程项目联系在一起，投标书应标明投标参考编号或
合同号。
11 In Case; In (the) Case of[❤38]
例1
In case Party B considers it necessary to employ a foreign auditor registered in another country to undertake annual financial verification and examination, Party A shall give its consent. All the expenses thereof shall be borne by Party B. 如果乙方认为需要聘请另一国注册审计师对年度财务进行审查，甲方应予以同意，其所需的一切费用应由乙方负担。
例2
In the case of carriage by sea or by more than one mode of transport including carriage by sea, banks will refuse a transport document stating that the goods are or will be loaded on deck, unless specially authorized in the credit.
Chinese version for reference:
如属海运或多种类型运输中包括海运，除非信用证特别授权，银行将拒受注明货装舱面或将装舱面的运输单据。
11 Be Liable for; Be Liable to[❤39]
例1
In case Party A and Party B of the joint venture company agree to continue the operation, the Party who fails to fulfill the obligations shall be liable for the economic losses thus caused to the joint venture company.
Chinese version for reference:
如果甲乙双方同意继续经营，违约方应赔偿合资公司的经济损失。
例2
A company may invest in other limited liability companies or companies limited by shares and be liable to the companies which it has invested in to the extent of the amount of capital invested in such companies.
Chinese version for reference:
公司可以向其他有限责任公司、股份有限公司投资，并以该出资额为限对投资公司承担责任
商务合同中英文模板
合同模板 Contract 合同签订及履约地: Place and Arbitration： 时间 Date and Time： 本合同由买卖双方订立，根据本合同规定的条款，买方同意购买，卖方同意出售下列商品。 This contract is made by the buyer and seller, the purchaser agrees to purchase and the seller agrees to sell the following goods under the terms of this contract. 1．卖方Seller******** 地址Address: Tel: Fax: 2．买方Buyer******** 地址Address:
Tel: Fax: 3．合同标的Subject of the Contract 4. 合同价格Contract Price
5. 支付条款Terms of Payment 5.1. 合同总价，xxxx,000.00 将按下述方式支付给卖方： The total CONTRACT PRICE of xxxx,000.00 shall be paid to SELLER as follows:
合同和发货时间表，允许分批发货。 The L/Cs shall be opened in favor of the SELLER by international commercial banks accepted by the SELLER. Partial shipments shall be allowed according to CONTRACT and delivery schedule. ?涵盖合同金额75 %（百分之柒拾伍）的L/C1将在收到合同项下预付款后5个月内开出，有效期为开证日后23个月。 The L/C1 for 75 % (eighty five) of the CONTRACT PRICE shall be opened within 5 months after receipt of the down payment under this CONTRACT at the latest
担保合同中英文对照
担保合同中英文对照供参考 担保协议Guarantee Agreement 担保合同，（适用于银行担保项下）(Applicable to Bank Guarantee) 1.作为委托人的（以下称“委托人”）和 2.作为保证人的XX银行股份有限公司（以下称“保证人”）签署。 This Guarantee Agreement (hereinafter referred to as the “Agreement”) is made and entered into as of (M/D/Y) between as the Client (hereinafter referred to as the "Client") and Branch, China XXXX Bank as the Guarantor (hereinafter referred to as the “Guarantor”). □本协议构成委托人与保证人签订的编号为年字第号的《授信 协议》（下称《授信协议》）的组成部分（本条适用的，在□中打“√”）。 The Agreement constitutes an integral part of the Credit Extension Agreement [20 ] No. (hereinafter referred to as the “Credit Extension Agreement”) between the Client and the Guarantor (if this paragraph applies, please click “√” in □). 鉴于： Whereas 1.委托人或被担保人（以下简称被担保人）与 于年月日签署了总金额为币的编号为的关 于的合同/ 标书（以下简称“合同”），或委托人 或被担保人参加了招标书编号为关于项目的投标 （以下简称“投标”）； 1. The Client or the Guaranteed (hereinafter referred to as the “Guaranteed”) signed No. Contract on / Bid Document totaling (Currency) (hereinafter referred to as the “Contract”) with on (M/D/Y), or the Client or the Guaranteed participated in the tender for Project with Bid Document No. (hereinafter referred to as the “Bid”); 2.委托人申请保证人为委托人或被担保人开立上述合同或投标项下以 为受益人（以下称“受益人”），金额币，编号 为的保函/备用信用证（下称“保函”）。 2. The Client applies to the Guarantor to open No. Letter of Guarantee/Stand-by LC (hereinafter referred to as the “Letter of Guarantee”) with an amount of (Currency) under the above Contract or Bid for the Client or the Guaranteed with as the Beneficiary (hereinafter referred to as the “Beneficiary”). 保证人同意应委托人申请按如下条件为委托人或被担保人向受益人开具上述保函： The Guarantor agrees to issue the above letter of guarantee in favor of the beneficiary for the Client or the Guaranteed upon request of the Client on the following terms and conditions: 第1条在保证人开立保函之前，委托人应根据保证人的要求： Article 1 Before the Guarantor issues the letter of guarantee, the Client shall upon request of the Guarantor:
中英文进口合同范本
中英文进口合同范本 以下是关于《中英文进口合同范本》，供大家学习参考！ Purchase Contract 合同编号(Contract No.): _______________ 签订日期(Date) :＿＿＿＿＿＿＿＿＿＿_ 签订地点(Signed at) :＿＿＿＿＿＿＿____ 买：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Buyer:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 电话(Tel):___＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿ 电子邮箱(-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 卖：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Seller:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿_＿ 电话(Tel):_＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿＿ 电子邮箱(-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 买卖双同意按照下列条款签订本合同： The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: . 货物名称、规格和质量： . 数量： 允许＿＿＿＿的溢短装 . 单价： . 总值： . 交货条件(Terms of Delivery) FOB/CFR/CIF＿＿＿＿＿＿＿ . 原产地国与制造商(Country of Origin and Manufacturers):
招商银行最高额抵押合同英文版Themaximummortgagecontract
THE MAXIMUM MORTGAGE CONTRACT October 2012
THE MAXIMUM MORTGAGE CONTRACT Contract No.: Mortgagee: China Merchants Bank Co., Ltd. (hereinafter referred to as Party A) Primary Personnel in Charge: Mortgagor (legal person or other organization): (hereinafter referred to as Party B) Legal Representative/ Primary Personnel in Charge: Mortgagor (natural person): ID No.: Whereas 1, The contract whose No. is signed by Party B(also as Credit Applicant) and Party A on (YMD)(hereafter referred as Credit Awarding Agreement), Party A is willing to provide to Party B line of credit(hereafter referred as “line of credit” )in (currency) in the amount of ( )(including other currency of the equivalent value) during the period of credit awarding (hereafter referred as “period of credit awarding” )from (YMD) to (YMD), or 2, The contract whose No. is signed by (hereafter referred as Credit Applicant) and Party A on (YMD)(hereafter referred as Credit Awarding Agreement ), Party A is willing to provide to Credit Applicant line of credit(hereafter referred as “line of credit” ) in(currency) in the amount of ( )(including other currency of the equivalent value) during the period of credit awarding (hereafter referred as “period of credit awarding” ) from (YMD) to (YMD).
外贸销售合同中英文对照(1)
可编辑可修改，欢迎下载 销售合同 SALES CONTRACT 卖方： The Seller ： Add 买方(The Buyer)： Add: 经双方确认订立本合同，具体条款如下： This sales contract is made out as per the following terms and conditions mutually confirmed by both parties: (5) 交货日期及运输方式 : Time of delivery: within 30days after the deposit, four containers each month. Mode of transportation ： shipping from SHENZHEN CHINA to INCHEON KOREA (6) 装运标记 : Shipping marks: N/M (7) 装运口岸 : ( 8) 目的口岸 : Port of loading: Shenzhen, China port Port of destination: Incheon port, Korea (9) 付款条件： (10) 包装：Packing Payment: 30% T/T in advance and balance payable against the copy of BL. Four containers each month. 备注：买方应根据卖方公司账户进行付款；如买方款项付到其它任何账户，卖方不承担任何责任。 Note: Buyer shall make a payment based on the seller ’s account, if the buyer any amount paid to the other account, the seller does not bear any responsibility . (11) 附加条款：（本合同其他条款如与本附加条款有抵触时，以本附加条款为准。）
商务合同-Contract-中英文
合同书 Contract 甲方： Party A: 乙方： Party B: 合同名称： Name of contract: 合同编号： Contract No.:
此合同由如下双方签定 The contract shall be signed by two parties as following: 1、（以下简称甲方） (hereinafter referred to as Party A) 2、（以下简称乙方） (hereinafter referred to as Party B) 此项目经甲乙双方友好协商，按国家经济合同法，现达成协议，其条款如下：The project is friendly negotiated by two parties according to national economic contract law. Now the agreement is reached with articles as following: 一、合同价格Contract amount 合同总金额为人民币（含17%增值税）xxx元。（大写：xxx）。 The total amount of the contract is xxxRMB (including 17% VAT) (in words: xxx). 二、工作范围Working scope 三、付款方式与条件Payment terms and conditions 3.1、合同生效后，甲方预付合同总价的30%。 Party A shall pay 30% of the total contract amount as down payment after the contract is signed and valid. 3.2、完成预验收后，乙方向甲方开具相应的发票，甲方预付合同总价的30%。 After the pre-acceptance, Party A shall pay 30% of the total amount against the invoice issued by Party B. 3.3、在最终客户完成终验收，甲方预付合同总价的30%。 Party A shall pay 30% of the total contract amount after the final customer’s final acceptance. 3.4、质保期为1年，年满后付合同总价的10%。 After the warranty period of 1 year, the last 10% of the total amount shall be paid. 3.5、合同金额包含往来运费。 The total contract amount shall include all transportation fees.
国际贸易合同中英文对照版
编号：_______________ 本资料为word版本，可以直接编辑和打 印，感谢您的下载 国际贸易合同中英文对照版 甲方：___________________ 乙方：___________________ 日期：___________________
英文进口合同范本-- 合同编号(Contract No.): 签订日期（Date） : ________________
m 甘售 inr (signed a ° ________ __ The Buyer _________________________________________
Address- C >5H (T E _) -—— ________ f
卖方: The Seller: 地址: Address: 电话(Tel):_ 传真(Fax): 电子邮箱(E-mail):
买卖双方同意按照下列条款签订本合同: The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: 1. 货物名称、规格和质量( Name, Specifications and Quality of Commodity ): 2. 数量(Quantity ): 允许的溢短装( % more or less allowed ) 3. 单价(Unit Price ): 4. 总值(Total Amount ):
投标担保协议(中英文)
GUARANTEE AGREEMENT FOR BID 本担保协议作为委托人的（以下称“委托人”）和作为保证人的银行（以下称“保证人”）签署。 This Guarantee Agreement (hereinafter referred to as the “Agreement”) is made and entered into as of (M/D/Y) between as the Client (hereinafter referred to as the "Client") and Branch, China Bank as the Guarantor (hereinafter referred to as the “Guarantor”). 本协议构成委托人与保证人签订的的《授信协议》（下称《授信协议》）的组成部分（本条适用的，在□中打“√”）。 The Agreement constitutes an integral part of the Credit Extension Agreement (hereinafter referred to as the “Credit Extension Agreement”) between the Client and the Guarantor (if this paragraph applies, please click “√” in □). 鉴于：Whereas 1.委托人或被担保人（以下简称被担保人）与于日签署了总金额为币的关于的合同/ 标书（以下简称“合同”），或委托人或被担保人参加了招标书关于项目的投标（以下简称“投标”）； 1. The Client or the Guaranteed (hereinafter referred to as the “Guaranteed”) signed Contract on Bid Document totaling (Currency) (hereinafter referred to as the “Contract”) with on (M/D/Y), or the Client or the Guaranteed participated in the tender for Project with Bid Document (hereinafter referred to as the “Bid”); 2.委托人申请保证人为委托人或被担保人开立上述合同或投标项下以为受益人（以下称“受益人”），金额币，编号为的保函/备用信用证（下称“保函”）。 The Client applies to the Guarantor to open No. Letter of Guarantee/Stand-by LC (hereinafter referred to as the “Letter of Guarantee”) with an amount of (Currency) under the above Contract or Bid for the Client or the Guaranteed with as the Beneficiary (hereinafter referred to as the “Beneficiary”).
常见的合同通用条款中英文对照
常见的合同通用条款 GENERAL TERMS AND CONDITIONS OF CONTRACT DATED日期 CONTRACT NAME合同名称 by and between合同双方 PARTY A NAME PARTY A甲方名称 and与 PARTY B NAME PARTY B乙方名称 TABLE OF CONTENT PRELIMINARY STATEMENT前言 1. DEFINITIONS定义 2. [OPERATIVE CLAUSES] 具体操作条款 3. CONDITIONS PRECEDENT如有必要，根据交易具体情况设定相应先决条件 4. REPRESENTATIONS AND WARRANTIES 陈述和担保［保证］ 5. TERM合同期限 6. TERMINATION合同终止 7. CONFIDENTIALITY保密义务
8. BREACH OF CONTRACT违约 9. FORCE MAJEURE不可抗力 10. SETTLEMENT OF DISPUTES争议的解决 11. APPLICABLE LAW 适用法律 12. MISCELLANEOUS PROVISIONS其他规定 THIS CONTRACT(“Contract”)is made in [city and province], China on this day of ,200 by and between [Party A name],[Party A entity form] established and existing under the laws of China, with its legal address at [address] (hereinafter referred to as “Party A”), and [Party B name], [Party B entity form] organized and existing under the laws of [Party Bjurisdiction of incoporation] with its legal address at [address] (hereinafter referred to as “Party B”). Party A and Party B shall hereinafter be referred to individually as a “Party ” and collectively as the “Parties”. 本合同于年月日由以下两方在［地点］签订： ［甲方名称］，一家根据中华人民共和国法律组建及存续的［甲方组织形式］，法定地址为［甲方法定地址］（以下简称“甲方”）： ［乙方名称］，一家根据［乙方所在国］法律组建及存续的［乙方组织形式］，法定地址为［乙方法定地址］（以下简称“乙方”）。 甲乙双方以下单独称为“一方”，合称为“双方”。 PRELIMINARY STATEMENT 前言 [add background information if appropriate]［视交易具体情况决定是否应介绍合同背景］ After friendly consultations conducted in accordance with the principles of equality and mutual benefit, the Parties have agreed to [describe subject matter of the Contract] in accordance with Applicable laws and the provisions of this Contract. 双方本着平等互利的原则，经友好协商，依照［相关法律名称］以及其他有关法律，同意按
[VIP专享]商务合同中英文翻译
汉译英 1.卖方将尽力在交货期内包装好所有货物。 The seller will endeavor to complete all packaging within time for the delivery date. 2.买方承担在货物运输和销售中的成本和费用。32 The buyer is responsible for the costs and charges incurred in the sale and transport of the goods. 3.卖方将一次性发送货物。到交货地的运输方式将由卖方决定。33 The seller will deliver the goods in a single shipment. The mode of transport to the point of delivery is at the seller’s discretion. 4.卖方应尽一切努力启运货物以便能及时交货。 The seller will make every effort to commence transport of the goods so that they will arrive by the delivery date. 5.如果推迟交货，卖方应立即告知买方推迟交货，预定的交货期和耽搁的理由。 If there is any delay, the seller will immediately notify the buyer of the delay, the expected time for delivery, and the reason for the delay. 买方有权就新的交货日期与卖方进行重新磋商，双方将以书面形式在协议上写下所做出的修改。或者，买方有权通知卖方终止合同。 The buyer will then have the option to renegotiate with the seller for a new delivery date, which the parties will confirm in writing as a modification to this agreement, or to notify the seller that the agreement is terminated. 6.为了自己的利益，买方将为运输中的货物投保。34 The buyer will obtain and pay, on its own account, for all insurance on the goods while in transit. 7.在货物运输前，保险人将把保险证明，如保单或由保险人所出具的其他证明交给买方。 Evidence of this insurance, in the form of a copy of the policy or other statement provided by the insurer, will be provided to the buyer before the goods are shipped. 8.买卖双方为自己的利益为货物所投保的险种将由其自行负担费用。 Each party is responsible for obtaining on its own account any other insurance coverage for the goods that he may desire. 9.如果买方已向卖方付款，在货物到达纽约港时货物的所有权将转移至买方。 Title to the goods will pass to the buyer at the time the goods are delivered to New York port provided the buyer has transmitted payment to the seller by that time. 10.如果延迟装运是由于买方无法及时提供此类证据，在这种情况下，卖方不违约。 If shipment is delayed because the buyer fails to furnish such proof timely, the seller will not be deemed to have breached the contract. 11.买方同意货物被运送到美国，并同意货物不会被运往其它国家。买方也不会在货物到达美国后再出口。 The buyer covenants that the goods will be shipped to and delivered in US and that the buyer will not ship or deliver the goods to any other country, nor will the buyer re-export the goods after delivery in US. 12.买方有权在卖方的营业地检验或让其代理人检验货物。36 The buyer is entitled to inspect, or to have its agent inspect, the goods at the seller’s place of business. 13.在交货后90天内，卖方可免费为买方换任何有瑕疵的货物，由此所产生的运输费用由卖方承担。 Within 90 days after delivery, the seller will replace free of charges, including the cost of transportations, any part of the goods found defective. 14.卖方应补偿买方任何由此类诉讼所承担的责任、支付的赔偿、花费及诉讼费用。37 The seller will indemnify the buyer against any liability, damage, or expenses incurred in connection with any such suit and will pay any judgment entered against the buyer in such suit. 15.这一协议的生效条件是：买方获得美国政府部门签发的进口许可证,卖方获得中国政府部门签发的出口许可证。38 This agreement is subject to the issuance of an import license to the buyer by the appropriate agency of US government and the issuance of an export license to the seller by the appropriate agency of China government. 16.如果任何一方通知另一方不想或不能履行协议，收到通知的一方有权撤销协议。 If either party notifies the other party that it will not, or is unable to, perform this agreement the party receiving notices is entitled to cancel the agreement. 17.为了使撤销有效，撤销的一方应通知另一方协议已撤销。撤销的日期是收到不履行协议通知的日期。 To make the cancellation effective, the party seeking to cancel must give notice to the other party that the agreement is deemed canceled. The date of the cancellation will be the date on which the party receives the notice of the nonperformance.
进口合同中英文对照contract
CONTRACT 合同号Contract 日期Date: 地点：Place: 卖方：The Seller: 地址：Address: TEL: FAX: 买方：The Buyer: 地址：Address: TEL: FAX: 本合同由买卖双方缔结，按照下述条款，卖方同意售出，买方同意购进以下商品： The Seller agrees to sell and the Buyer agrees to buy the under mentioned goods subject to terms and conditions set forth hereinafter as follows: 1.商品名称及规格NAME OF COMMODITY AND SPECIFICATION: 2.数量QUANTITY: 3.单价（包装费包括在内）UNIT PRICE (PACKING CHARGES INCLUDE): 4.总值: TOTAL VALUE: USD 5.包装（适于海洋运输）PACKING (SEAWORTHY):
6.生产国别及制造商COUNTRY OF ORIGIN & MANUFACTURE: 7.装运时间：TIME OF SHIPMENT: 8.装运口岸：PORT OF LOADING: 9.目的口岸：PORT OF DESTINATION: 10.装运唛头：SHIPPING MARKS 11.付款条件：Terms of Payment A. 买方于装运时间前天通过银行开出以卖方为受益人的不可撤销的信用证，卖方在装船启运后凭本合同条款12所列单据在开证银行已付货款。信用证有效期为装船后15天截止。 A. days prior to the time shipment, the Buyer shall open with the Bank of , an irrevocable Letter of Credit in favour of the Seller payable at the issuing Bank against presentation of the shipping documents as stipulated under Clause 12 of this Contract after departure of the carrying vessel. The said Letter of Credit shall remain in force till the 15th days after shipment. B. L/C AT SIGHT 见票即付信用证（或者根据实际情况改为TT） 12.装运单据Shipping Documents: DETAILED IN THE L/C 按信用证所列 13.延期交货及罚款：除不可抗拒原因外，如卖方不能如期交货，买方有权撤销或解除该订单，或经买方同意在卖方缴纳罚款的条件下延期交货。买方可同意给予卖方天优惠期。每迟延一天卖方需向买方支付订单总价款%的违约金。罚款自第天起计算。 Delayed Delivery and Penalty: Should the Sellers fail to effect delivery on time as stipulated in this Order owing to causes other than Force Majeure as provided for in Clause 11 of this Order, the Buyers shall have the right to cancel or terminate the order .The Sellers may, with the Buyers’consent, postpone delivery on payment of penalty to the Buyers. The Buyers may agree to grant the Sellers a grace period of days. Delay each day, the Seller need to pay % of the price （the compensation）to the Buyer. Penalty shall be calculated from the 16th day. 13、仲裁：凡因本合同引起的或与本合同有关的任何争议，均应提交中国国际经济贸易仲裁委员会天津国际经济金融仲裁中心，按照申请仲裁时该会现行有效的仲裁规则进行仲裁。仲裁裁决是终局的，对双方均有约束力。 Arbitration: Any dispute arising from or in connection with this CONTRACT shall be submitted to CIETAC Tianjin International Economic and Financial Arbitration Center for arbitration which shall be conducted in accordance with the Commission’s arbitration rules in effect at the time of applying for arbitration. The arbitral awards is final and binding upon all parties 。 14. 商检条款INSPECTION:
个人消费贷款借款担保合同中英
个人消费贷款借款担保合同(中英文) Individual Consumption Loan Borrowing Contract 借款人：Borrower 贷款人：Lender 抵押人：Mortgagor 保证人：Surety 出质人：Pledgeor 为明确各方权利和义务，根据《合同法》、《贷款通则》和其他有关法律、法规，订立本合同。 This Contract is made in line with the Contract Law of the People's Republic of China and The General Provisions of Loans of the People's Bank of China to specify the rights and obligations of parties involved. 借贷条款Loan Borrowing Clause 第一条借款金额。见36.1 Article 1. Amount of loan: Refer to 36.1 第二条借款用途。见36.2 Article 2. Purpose of loan: Refer to 36.2 第三条借款期限。Article 3. Life of loan 3．1见36．3。3.1 Refer to 36.3 3．2借据或贷款凭证是本合同不可分割的组成部分。借款的实际放款日和还款日以借款人、贷款人双方办理的借据或凭证上所记载的日期为准。除日期外，借据或凭证其他记载事项如与本合同不一致的，以本合同为准。 3.2 A certificate of indebtedness or a loan voucher is an integral part of this Contract. The date of advance and payment due date shall follow the date specified on the certificate of indebtedness or loan voucher . Where there is any inconsistency between the stipulations on the certificate of indebtedness or loan voucher and the Terms and Conditions on this Contract except date, the latter shall prevail. 第四条借款划付。在借款人办妥借款手续后5个营业日内将全部款项划至借款人指定的账户，划付次数、时间、金额见36．4 。 Article 4 Transferring of loan. The full amount of loan shall be transferred to an
中英文对照版合同翻译样本
1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Trading Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract th This Contract is entered into this 5 day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿ This Agreement was made on the＿day of＿ 19＿, BETWEEN ＿(hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the