中英文对照工程施工合同

工程施工合同

Contract

合同编号( Contract NO. )：

签订日期( Date )：

发包方（简称甲方）

Party A:

承包方（简称乙方）：

Party B:

根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。

According to “P.R.C Contract Law”, and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect.

1.工程概况

Project overview

1.1工程名称：

Project name:

1.2工程地点：

Project location:

1.3工程范围：

A. 新研发中心和新厂房的网络综合布线系统的施工；

B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。

Project contents:

A. The new R & D and new plant construction of network cabling systems;

B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems.

1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。

Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.

1.5工程造价：合同工程总造价为￥元（CNY），人民币大写

Project cost：Total project cost is yuan ( CNY ).

详细合同价格表见附件报价清单。

Detailed contract price list see attached quotation list.

在详细设计和施工过程中，若工程量发生变化，按合同单价相应调整工程造价；若材质发生变化，按双方商定的补充协议调整工程造价。

In the detailed design and construction process, if the project quantity changes, according to the contract price adjustment project cost; if the material is changed, the supplemental agreement agreed by both parties for adjustment of engineering cost.

2.付款方式

Terms of payment

2.1由乙方向甲方提供指定帐户、甲方以支票方式或银行转账方式向乙方结算合同款；Party B shall provide the designated account to party A, Party A by check or bank transfer to pay the contract payment to Party B.

2.2本合同生效后，甲方付给乙方合同总价的40%作为工程预付款，即￥元；After the signing of this contract, Party A shall pay to Party B 40% of the total contract price as the project advance payment;

2.3数据中心及网络布线系统工程完工并且双方签订工程验收报告后7天以内，甲方付给乙方合同总价的55%，即￥元；

Data center project and network cabling systems engineering completed and signed

a project acceptance report by both parties within 7 days after, Party A shall pay to Party B 55% of the contract price.

2.4工程竣工后3个月内，甲方支付给乙方剩余的合同款，即￥元；

After the completion of the project within 3 months, Party A shall pay to Party

B the remaining contract price.

3.双方职责

Responsibilities of the parties

3.1甲方职责：

Responsibilities of party A:

a. 及时以书面形式通知乙方本工程具备开工条件的时间;

Timely written notice to Party B the conditions of this project have the time to start;

b. 协助乙方办理进驻施工现场所需人员证件、批件等有关手续；

To assist Party B to enter the construction site personnel required documents, approval documents and other relevant procedures;

c. 为乙方提供现场工程办公室和足够的现场仓库；

To provide on-site engineering office and sufficient field warehouse;

d. 积极协助乙方施工，协调施工时与各部门的配合，并负责提供工程所需的现场平面图及建筑结构图。

Actively assist Party B construction, coordination with various departments, and responsible for providing the needed for the project site plans and architectural drawings.

e. 及时按合同规定之付款进度向乙方支付工程款项。

Timely according to the terms of the contract payment schedule to pay Party B project funds.

3.2乙方职责：

Responsibilities of party B:

a. 乙方在工程开始前应组织有关人员研究和熟悉图纸，参与设计交底，安排施工总进度计划并提交给甲方；

Party B before the project begins shall organize relevant personnel to study and be familiar with drawings, involved in the design work, arrangement of construction general schedule plan and submit to Party A;

b. 向甲方或项目监理提供所购各种产品、设备的技术资料，接受进场检验；

To the party A or project supervision to provide the purchase a variety of products, equipment, technical information, accept entry inspection;

c. 遵守甲方或监理方对施工现场的有关规定；

Abide by the party or the supervision on construction site of the relevant provisions;

d. 按时完成乙方所承担的施工任务，保证工程施工质量。

Timely completion of construction tasks undertaken by Party B, to ensure construction quality.

4.施工与工程设计变更

Construction and engineering design change

4.1乙方在施工中要根据国家颁发的施工验收规范和质量检验标准，以及设计要求进行，要求全部工程达到合格标准。

On the construction of Party B according to the country issued construction acceptance norms and quality inspection standards, as well as the design requirements, all project achieve the qualified standard.

4.2在施工中，要坚持按照设计文件和施工图纸施工，任何一方不得随意变更设计，如出现窝工、返工和材料损失，以及增加劳动力成本等，由于甲方的原因造成的，损失由甲方承担，由于乙方的原因造成的，损失由乙方承担。

During construction, to adhere to the design documents and construction drawings of the construction, any party shall not be arbitrarily changed design, such as

the emergence of idleness, rework and loss of material, as well as an increase in labor cost, as the party A 's cause, loss borne by the party A, the Party B causes, losses shall be borne by Party B.

4.3在施工中，若甲方A有变更设计文件的要求，应书面通知乙方；若乙方发现设计文件有错误或严重不合理的地方，也应书面通知甲方，双方商定并修改设计文件和图纸后方可继续施工。

During the construction, if the party A to change the design document, shall give a written notice to Party B; if Party B is found the design documents are wrong or serious unreasonable place, should also be written notice to Party A, both sides agreed and modify design drawings and documents before it can continue to construction.

4.4在施工过程中，如遇下列情况，需顺延工期，双方应及时进行协商，并通过书面形式确定顺延期限：

In the process of construction, in case of the following circumstances, be extended period, both parties shall timely consultations, and through the written form to determine the extension of the time limit:

a.因天灾或人力不能抗拒的原因被迫停工的；

Because of natural disaster or the manpower irresistible reasons forced shutdown;

b.因甲方提出变更计划或变更施工图而不能继续施工的；

Because party A proposed changes to the plan or change the construction graph therefore cannot continue construction;

c.乙方不能按期供设备或所供材料或者设备不合规格要求，被迫停工或不能顺利施工的；Party B fails to supply equipment or for the materials or equipment of different specifications, was forced to shut down or not smooth construction;

5.竣工验收与售后服务

Final acceptance and after-sales service

5.1乙方必须严格执行隐蔽工程验收制度，凡隐蔽工程完成后，必须经过验收并作好记录(隐蔽工程指墙内、吊顶内的管线施工等）。

Party B must strictly enforce the hidden work system, where the hidden work has been completed, must pass inspection and make records (hidden works refers to the wall, the ceiling inside the pipeline construction, etc.).

5.2整体工程竣工后，乙方向甲方提交竣工文档并提交书面验收申请。甲方接到申请后7日内组织有关人员按照合同内容和事先约定的验收条款进行项目验收，并出具双方签字的验收报告。如甲方不能按期组织验收，须提前通知乙方，并与乙方另行商定验收日期，但甲方必须承认乙方的竣工时间。甲方推迟验收，其间所发生的管理费和各项损失均由甲方负担。如果提交验收申请后一个月仍未能完成验收，则以竣工之日作为系统的保修开始日期。

When the whole project is completed, Party B shall submit to party A complete

documentation and submit a written acceptance application. Party A shall within 7 days after receiving the application organize relevant personnel in accordance with the contract contents and the prescribed inspection clause of project acceptance, and issue the report signed by both parties. If Party A fails to organize acceptance, shall inform Party B in advance, and Party B to be agreed date of acceptance, but party A must acknowledge party B completion time. party A delayed acceptance, during which occurred in the management fees and all losses shall be borne by Party A. If the submission of acceptance application one month after failed to complete acceptance, the completion date as the system warranty start date.

5.3工程验收合格后进入质保期。质保期为验收合格之日起12个月。在质保期内，乙方应对系统除人为因素外的所有故障负责免费维修或更换。

Project after acceptance into the warranty period. Warranty period from the date of acceptance of 12 months. During the warranty period, Party B shall system in addition to human factors all fault is responsible for free repair or replacement.

5.4在质保期内，乙方做到对甲方求援电话2小时内响应，8小时内抵达现场并着手解决问题。质保期结束后，乙方对系统进行有偿维护。有偿维护的费用由双方协商。

During the warranty period, Party B shall do to help telephone response within 2 hours, 8 hours to arrive at the scene and set about solving the problem. After the end of the warranty period, Party B on the system paid maintenance. Paid maintenance costs through consultation by the two parties.

6.技术服务和培训

Technical service and training

6.1由乙方按技术培训大纲负责对甲方的有关操作人员和维修人员进行使用级培训。通过培训，使甲方的受训人员能掌握系统设备的配置，能进行正确操作和日常维护及一般常见故障排查。接受培训的人员由甲方确定，日期由甲乙双方共同商定。

Party B according to the technical training program for Party A 's operators and repair personnel to use class training. Through training, the trainees can grasp the party system equipment configuration, can correct operation and routine maintenance and common trouble shooting.Trained personnel were identified by the party A, the date mutually agreed by both parties.

6.2在保修期内，乙方提供两次上门巡检服务，包括各系统运行状况的查看、记录，以及必要的设备维护。

During the warranty period, Party B shall provide two on-site inspection services, including the status of system view, recording, and the necessary equipment maintenance.

6.3乙方为甲方免费提供网络综合布线系统和数据中心的技术咨询服务。

Party B shall provide free network cabling system and data center technical advisory services.

7.违约责任

The liability for breach of contract

7.1乙方提供货物的质量或规格不符合合同约定，行业规格或政府的法令法规的要求的，甲方可以根据货物的性质以及损失大小，要求乙方承担修理，更换，退货，减少价款等责任。

Party B shall provide the quality or specifications of the goods does not conform to the contract specifications, industry or government regulatory requirements, Party A may according to the nature of the goods and the loss of size, B should bear the repair, replacement, return, reduce cost.

7.2乙方除因受《中华人民共和国合同法》规定的不可抗力因素影响外，如果未能按计划施工，则乙方在竣工之日前，每日应按甲方所支付合同款的1‰（大写：千分之一）赔偿甲方损失。

Party B except due to" P.R.C Contract Law" provisions of force majeure factors, if the construction not on schedule, then Party B in the completion date, daily should be paid by Party A contract to 1‰ (in words: 1/1000) compensation for the loss of Party A.

7.3在履行合同过程中，如果乙方提前获知有不能按时交货或提供服务的情况，应及时以书面形式将不能按时交货的理由、预期延误时间通知甲方。甲方收到乙方通知后，认为其理由正当的，可酌情延长交货时间。

During performance of the contract, if Party B know ahead of time has not delivered on time or to provide service, should be promptly in writing of the reasons for

not delivered on time, anticipated delay time notify party. Party A received notification, think its reason, could be appropriate to extend the time of delivery. 7.4若由于甲方更改设计需求、未确认材料或设备型号、未确认施工方案而导致设备订货周期推迟，因此导致的延迟交货，乙方不负担任何责任。

If due to Party A to change the design demand, did not confirm material or equipment models, unrecognised construction scheme caused by equipment order cycle time delay, thus causing the delay of delivery, Party B does not bear any responsibility. 7.5甲方在合同规定的付款期限内未能及时付款，视为甲方违约。甲方每日按合同款项的千分之一赔偿乙方损失。

Party A in the contract payment period failed to timely payment, regarded as a breach of contract. Party A according to the contract sum 1/1000 daily compensation for any loss of Party B.

7.6甲乙任意方因第三者的原因造成违约的，应向对方承担违约责任。

Any party for the third party reasons for default, shall be liable to the other party for breach.

8.合同的变更

The modification of Contract

合同需在甲乙双方公平协商，达成一致的条件下进行变更，变更的内容需以文字正本形式

经双方授权人签字并盖章后生效。一切变更内容作为附件存在与合同正本具有相同的法律效力。

Any modification must on the basis of fair negotiation and be accepted by both sides. The formal file of modified contract should be validating after signed and stamped by authorized person of both sides.All change to the content as an attachment with the original contract have the same legal effect.

9.仲裁

Arbitration

双方对于任何合同内容上的争议首先依据《中华人民共和国合同法》进行协商解决，如不能解决，可由北京市合同仲裁委员会仲裁解决。

A ny dispute of the contract should be negotiate and solved at first base on “P.R.C Contract Law ”, if it is can not solved by discuss of both sides, the final arbitration was m ade by “Contract Intermediation committee of Beijing”.

10.合同使用的文字极其效力

Effectiveness of the Character

合同以中英文两种文字书写，具有相同的法律效力，任何内容上的由于语言造成的矛盾，以中文为有效文字。

The contract was written in English and Chinese, they have the same effectiveness

in law, Chinese is the final valid character when any difference of understanding produced.

11.合同未尽事宜的说明

The explain items not included in contract

合同未尽事宜，由甲乙双方依据《中华人民共和国合同法》协商解决。

The items that are not included in the contract should be negotiated by both side on the base of “P.R.C Contract Law ”.

12.其它

Others

本合同一式四份，甲乙双方各执二份。双方授权人签字盖章起合同生效。

Four copies of the contract, both parties shall keep two copies. The valid data start from the contract signed and sealed and sealed by authorized person of both sides.

合同附件：报价清单

Appendix: list of quotations

甲方盖章：乙方盖章：

Seal of Part A Seal of Part B

地址：地址：Address Address

授权人签字：授权人签字：Signature Signature

电话：电话：

Tel Tel

传真：传真：

Fax Fax

邮编：邮编：

Post Code Post Code

常见的合同通用条款中英文对照

常见的合同通用条款 GENERAL TERMS AND CONDITIONS OF CONTRACT DATED日期 CONTRACT NAME合同名称 by and between合同双方 PARTY A NAME PARTY A甲方名称 and与 PARTY B NAME PARTY B乙方名称 TABLE OF CONTENT PRELIMINARY STATEMENT前言 1. DEFINITIONS定义 2. [OPERATIVE CLAUSES] 具体操作条款 3. CONDITIONS PRECEDENT如有必要，根据交易具体情况设定相应先决条件 4. REPRESENTATIONS AND WARRANTIES 陈述和担保［保证］ 5. TERM合同期限 6. TERMINATION合同终止 7. CONFIDENTIALITY保密义务

8. BREACH OF CONTRACT违约 9. FORCE MAJEURE不可抗力 10. SETTLEMENT OF DISPUTES争议的解决 11. APPLICABLE LAW 适用法律 12. MISCELLANEOUS PROVISIONS其他规定 THIS CONTRACT(“Contract”)is made in [city and province], China on this day of ,200 by and between [Party A name],[Party A entity form] established and existing under the laws of China, with its legal address at [address] (hereinafter referred to as “Party A”), and [Party B name], [Party B entity form] organized and existing under the laws of [Party Bjurisdiction of incoporation] with its legal address at [address] (hereinafter referred to as “Party B”). Party A and Party B shall hereinafter be referred to individually as a “Party ” and collectively as the “Parties”. 本合同于年月日由以下两方在［地点］签订： ［甲方名称］，一家根据中华人民共和国法律组建及存续的［甲方组织形式］，法定地址为［甲方法定地址］（以下简称“甲方”）： ［乙方名称］，一家根据［乙方所在国］法律组建及存续的［乙方组织形式］，法定地址为［乙方法定地址］（以下简称“乙方”）。 甲乙双方以下单独称为“一方”，合称为“双方”。 PRELIMINARY STATEMENT 前言 [add background information if appropriate]［视交易具体情况决定是否应介绍合同背景］ After friendly consultations conducted in accordance with the principles of equality and mutual benefit, the Parties have agreed to [describe subject matter of the Contract] in accordance with Applicable laws and the provisions of this Contract. 双方本着平等互利的原则，经友好协商，依照［相关法律名称］以及其他有关法律，同意按

中英文对照版合同翻译样本

1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Tradi ng Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract This Contract is entered into this 5th day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿This Agreement was made on the＿day of＿19＿, BETWEEN ＿ (hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the Seller has agreed to sell and the buyer has agreed to buy ＿ (hereinafter referred to as the Goods ) the quantity, specification, and price of which are provided in Schedule A. IT IS HEREBY AGREED AS FOLLOWS: 5.Contract For Joint-Operation Enterprise ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party A”) AND ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registere d office at (hereinafter called “Party B”) Party A and Party B (hereinafter referred to as the “Parties”) agree to jointly form a Co-operation Venture Company (hereinafter referred to as the “CVC”) in accordance with “the Laws of the People’s Republic of C hina on Joint Ventures Using Chinese and Foreign Investment” and the “Regulations for the Implementation of the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and other applicable laws and regulations. 6.MODEL CONTRACT Contract No. Date: Seller: Signed at: Address: Cable Address: Buyer: Address: Cable Address: The Seller and the Buyer have agreed to conclude the following transactions according to the terms and conditions stipulated below: https://www.wendangku.net/doc/da5214794.html, of Commodity: 2.Specifications: 3.Quantity: 4.Unit Price: 5.Total Price: U.S.$: 6.Packing: 7.Time of Shipment: days after receipt of L/C. 8.Loading Port & Destination Port: From via to . 9.Insurance:

2.劳务合同英文版

EMPLOYMENT CONTRACT Contract No.: Employer (Party A): Employee (Party B): This Employment Contract is made and entered into on the day of______ , ______by and between______ (hereinafter referred to as“Party A”) and ______ (hereinafter referred to a s“ Party B”). 1. Obligations of T wo Parties Party A hereby employs Party B and Party B hereby accepts to be employed by Party A to serve and perform the duties required of him in the job category provided below: (1) ______ (2) ______ (3) ______ … 2. Service Period The term of this Contract shall be for the period of______, commencing upon ______, ______and ending on ______, ______. 3. Working Hours and Working Days Party B’s work days, hours and workweek shall be______ to ______, from ______ to______ , for a total______ hours per week. 4. Salary

国际贸易合同中英文对照版

编号：_______________ 本资料为word版本，可以直接编辑和打 印，感谢您的下载 国际贸易合同中英文对照版 甲方：___________________ 乙方：___________________ 日期：___________________

英文进口合同范本-- 合同编号(Contract No.): 签订日期（Date） : ________________

m 甘售 inr (signed a ° ________ __ The Buyer _________________________________________

Address- C >5H (T E _) -—— ________ f 火客a (E —ma=H ___________________________

卖方: The Seller: 地址: Address: 电话(Tel):_ 传真(Fax): 电子邮箱(E-mail):

买卖双方同意按照下列条款签订本合同: The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: 1. 货物名称、规格和质量( Name, Specifications and Quality of Commodity ): 2. 数量(Quantity ): 允许的溢短装( % more or less allowed ) 3. 单价(Unit Price ): 4. 总值(Total Amount ):

英文销售合同_中英文对照销售合同范本

英文销售合同_中英文对照销售合同范本英文销售合同_中英文对照销售合同范本(一) SALES CONTRACT 合同编号： Contract NO: 签订地点： Signed at: 签订日期： Date: 买方： The Buyers： 卖方： The Sellers： 双方同意按下列条款由买方售出下列商品：

The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below： (1)商品名称、规格及包装 (1)Name of Commodity ,Specifications and Packing (2)数量 (2)Quantity (3)单价 (3)Unit Price (4)总值 (4)Total Value (装运数量允许有 %的增减) (Shipment Quantity %more or less allowed) (5)装运期限：

(5)Time of Shipment： (6)装运口岸： (6)Port of loading： (7)目的口岸： (7)Port of Destination： (8)保险;由方负责，按本合同总值110%投保_____险。 (8)Insurance：To be covered by the___for 110% of the invoice value against_______. (9)付款：凭保兑的、不可撤销的、可转让的、可分割的即期有电报套汇条款/见票/出票____天期付款信用证，信用证以_____为受益人并允许分批装运和转船。该信用证必须在______前开到卖方，信用证的有效期应为上述装船期后第15天，在中国______到期，否则卖方有权取消本售货合约，不另行通知，并保留因此而发生的一切损失的索赔权。

劳动合同书(中英文对照)

乙方：姓名：性别：出生日： Party B：Name Sex：Date of Birth： 家庭住址：所属地区： Address：Sub District： 通讯地址：电话： Post Address：Contact Phone： 维蒙特工业（广东）有限公司（甲方）聘用乙方为甲方劳动合同制员工。根据《中华人民共和国劳动法》、《广东省劳动合同条例》、《维蒙特工业（广东）有限公司章程》以及中国和广东省已颁布并可公开得到的有关法律法规，甲乙双方本着自愿平等、协商一致的原则，签订本合同。 According to the Labor Law of the P.R. China, as well as the Personnel Regulations of Guangdong Labor Contract, Valmont Industries (Guangdong) Ltd. employs Party B (the employee) as a contract employee. Both parties to this contract sign on the basis of equity, free will, and mutual benefits. 第1条合同期限 Contract Period 1.1本合同有效期自200___年___月___日至200___年___月___日止（含试用期____个月）。 The contract period of employment will be valid from ____/____/_____ (M/D/Y) to ____/____/______ (M/D/Y). During which the period of _______ months will be considered as probationary employment. 1.2在试用期内，甲方发现乙方不符合录用条件的，甲方可以即行解除本合同。 Party A has the right to terminate Party B’s Labor Contract immediately without notification if Party B does not prove to be suitable through the period of probationary employment. 第2条工作岗位、任务 Positions, duties & Responsibilities 2.1 甲方安排乙方在________________部门_____________岗位工作，覆盖岗位为_________________ Party A (the employer) employs Party B (the employee) in the capacity of 2.2 乙方必须按照甲方规定的岗位职责和要求全面完成指标和任务，并接受甲方对其进行的有关考核测评。 Party B is required to fulfill his/her responsibilities completely and accurately as described by Party A and accept performance measurement handled by Party A 2.3 甲方根据生产经营需要及乙方的工作技能和表现，可变更乙方的工作，乙方须服从甲方的调动，如无正当理由，不服从调动 者，甲方可辞退乙方，解除其劳动合同。 Party A has the right to adjust Party B’s position according to the actual business situation and the performance of Party B. Party B must accept Party A’s arrangement. 第3条工作条件、劳动保护 Labor Conditions & Labor Protection 3.1 甲方实行每周40小时工作制。对特殊岗位可实行不定时工作制。 Party B’s normal working time will not exceed 40 hours per week, whereas it’s flexible for some special position holders. 3.2 甲方因生产经营原因需要乙方加班时，乙方应服从。同时甲方应按规定支付乙方加班费报酬作补偿。 If it is necessary for Party A to request Party B to put in overtime, Party B must be subordinated to request of Party A. Party A shall provide Party B with economic compensation according to relevant regulations. 3.3 甲方为乙方提供必要的工作条件，根据国家劳动法则提供符合中国政府规定的劳动安全卫生条件和提供必要的劳动保护用品， 保证乙方在人身安全及个体不受危害的环境条件下工作，对女职工及未成年工按《劳动法》的规定酌情予以特殊劳动保护。 Party A must provide Party B with a safe and non-toxic working environment, necessary safety measures to guarantee safe working conditions of Party B, according to National Safety and Sanitation Standards. Party A shall provide special protection measures for female and underage employees according to the Labor Law. 3.4 甲方认为乙方的健康状况将会对工作或其他员工造成不利影响时，甲方有权按制度采取相应的措施，并有权要求乙方进行健 康检查，乙方不应拒绝。 If Party A thinks Party B’s healthiness will effect to the work or other staffs, Party A will have the authority to correspond and will have the authority to ask Party B to have a physical check-up, at same time the Party B should not to refuse. 3.5 乙方在被聘用期间，甲方负责对乙方进行岗位职责、技能、安全规程、职业道德及相关规章制度的教育和培训，乙方须积极 配合，并根据岗位职责要求努力提高自身的技能。 Party A is in charge of various training such as technical training, Position principles, safety operations, Company’s regulations and provision, etc. within the employment period. Party B shall accept the training with positive attitude for raising his/her work efficiency. 第4条劳动报酬 Payroll

外贸合同中英文对照

S ALES CONTRA C T NOo : BS0812 5 DATE： NOV. 6 , 2008 THE S ELLER： BLUE SKY INTE R NATI0 NAL TRADING CO o ,LTD ? 118# 5TH NORTH RI NG ROAD, BE I GINQ P.R. CHINA THE BUYER： STAR CORPORATION 5 KINGROA D DU BAI, UAE T h i s C o ntra c t is made by and b e tw e e n the Buyer and S e llei; wh e reby the Buy e r agree to bu y and the Seller a gree to sell the un d ermen tioned c ommodity a c c ording to t lie term s a nd co n ditions st i pulat e d b e 1 o w 数量和金额可以上下浮动5% P A C K I NG： 2 0 piece s of Baby B 1 anke t s a r e p acked i n one

expo r t sta n dar d c a rt o n, solid co 1 or and s ize i n the s a me c a r ton. 包装：2 0条童毯被装进-项输出品标准硬纸盒、一样颜色利尺寸的装在相同的硬纸盒。 MAR KS： Shipping m a rk i n c 1 udes S TAR ,S/C No。,sty 1 e No o , port o f des tina t ion and c a r t on N o .陵头：运输吱头包括S TA R （公司名）、合同（sal e s contract）号码，款式号码，目的港和纸箱号码 Side mark m u st s how the co 1 o r t the s i ze of c a rton and p i ece s p e r carto n ? 侧唆头必须显示纸箱颜色，规格和每箱（童毯）条数 T I ME OF SHIPMENT：装运期 Wi t liin 60daysupon receip t o f the L / C wh i c h acc ord with relevant c buses o ft h i s Contract。收到符合合同的信用证^六十天内 POR T OF LOADI NG AND DESTINAT I ON：FromTianj i n, Chi nato Dub a i, UAE 装运港目的港 T r an s shipment i s all owed an d p artial shipme nt i s pro h i b i te d o 转运被允许，而且分批装运被禁止. IN S URANCE： To beeffecte d b y the Sei 1 e r for 1 1 0% o f inv o i c e value c ov e r in g Al 1 Ris k s and War Risk s a s p er CIC o f PICC d ated 01/01/1981.保险：卖方按合同金额的110%投保包含的一切险和战争险依照1981年的P I CC规则的CIC条约。 TERMS OF PAYMENT： By irrev o c able Let t er of Cre d i t at 60 d ay s a f t er s igh t, reaching the S e 1 1 er not 1 a te r t han Nov.30, 200 8 an d rem a in i ng v a li d f or n e gotiation in Ch i n a fo r f ur t her 15 days after th e a ffected s hipment o I n c a se of late ar r i v al of the L/C, the Se 1 1 er s hall not be liable for any d e lay i n ship me n t and shall ha v e the right t o res c i n d the c o ntra c t and / o r c 1 aim for damages0付款期限：不可撤销信用证，见票后6 0天付款.卖方收到信用证不得晚于08年月30号.偿付通知议付在中国装船后15天内提交单据，如果信用证迟到,卖方将不负责装船中的任何延迟而且将有权利废止合同和I或损害要求（赔偿）。 DOCUMENTS：文件 +Si g n e d invoice i n t r ipli cate, one or i g i nal o f w hicli s lioul d b e c ertifiedby Chamber of Com mere e o r CCPIT an d legalize d b y UAE em b ass y/co n su 1 ate in sei 1 er's country ? +签署的单据一式三份，一份正本应该被商会或CC PIT （贸促会）检定而且在卖方的国家被阿拉伯联合大公国大使馆I领事法律上认为正当。 +Ful 1 set （3/3） of c 1 ean on board o cean b i 11 o f lading ma r k e d <4fr e ight pr e paid" made out t o orde r blank en d o r sed n o t i fying th e app 1 icant. +全套（3 I 3）清洁海运提单标记"船货预付”空白抬头提单通知申请人。 +In s u r a n ce polic y i n dup lica te end o r s ed in b 1 a nk. +保险单一式两份空白背书。 +P a c k ing list i n t r i p 1 i c ate o +包装目录一式三份 + Cer t if i c at e of ori g in c erti f i e d by Cham b er of C o mmerce o r C CP I T and 1 e ga 1 i zed by U AE em b as s y/consulate in s e lie r "s countr y ?

中英文对照工程施工合同2范本

工程施工合同 Contract 合同编号( Contract NO. )： 签订日期( Date )： 发包方（简称甲方） Party A: 承包方（简称乙方）： Party B: 根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。 According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect. 1.工程概况 Project overview 1.1工程名称： Project name: 1.2工程地点： Project location: 1.3工程范围： A. 新研发中心和新厂房的网络综合布线系统的施工； B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。 Project contents: A. The new R & D and new plant construction of network cabling systems; B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems. 1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。 Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.

劳务协议书-Labor-Service-Agreement-中英文对照 派遣员工劳务合同(中英文)最新合同版本

劳务协议书 Labor Service Agreement 甲方（单位名称）： Party A (Company Name): 乙方（劳务者姓名）： Party B (Service provider Name): 性别：男身份证/护照号码：联系电话： Gender: Male ID/Passport No.: Tel No.： 家庭住址： Home Address: 根据《中华人民共和国民法通则》、《中华人民共和国合同法》和有关规定，甲乙双方经平等协商一致，自愿签订本劳务协议，共同遵守本协议所列条款。 According to the "General Principles of Civil Law of the People's Republic of China", "Contract Law of the Peop le's Republic of China” and relevant regulations, after equal negotiation, Both parties agree to sign and comply with this labor service agreement 第一条乙方承担的劳务内容为：。甲乙双方可另行约定岗位具体职责及要求，详见职责说明书，附件一。 Article 1 Party B’s Job duty is：Both parties agree on Job duties and requirement as in, Annex I, Job Description. 第二条乙方的工作地点为：,根据甲方工作需要，经甲乙双方协调一致，可变更工作地点。Article 2 Working location of Party B is: , which can be changed on the basis of mutual agreement as per Par ty A’s business requirements. 第三条本协议期限为自年年月日生效，至年年月日终止。其中试用期从/ 年/ 月/ 日起至/ 年/ 月/ 日止。 Article 3, The Agreement period is from to . The probation is / month(s), from / to / . 第四条在协议期间，甲方的责任和义务是：

外国人劳务合同简易中英文版

编号：_____________外国人劳务合同 甲方：___________________________ 乙方：___________________________ 签订日期：_______年______月______日

甲方： Party A： 地址： Address： 乙方Party B： 性别Gender： 国籍Nationality： 护照号码Passport No.： 在华居住地址Address (Beijing)： 联系方式Contact： 其他紧急联络人Contact person in case of emergency： 一、雇佣期限 Ⅰ Employment term 雇佣期限为年，自年月日起至年月日止The employment term is year(s), lasting from to . 二、雇佣内容及工作时间 Ⅱ Content and working hours 2.1 甲方根据工作需要，安排乙方完成以下内容的工作任务： Party A gives Party B the following work assignments according to its operating requirements:

工作内容Job responsibilities： 工作地点Place： 2.2 工作时间：乙方每日工作时间不超过8小时，平均每周工作不超过40小时，每周休息日为周六、日。 Party B works no more than 8 hours per day, no more than 40 hours per week, and Saturday and Sunday are set as weekly rest days. 三、报酬及其他福利 Ⅲ Remuneration and other welfare benefits 3.1 乙方的报酬为税前元/月，大写： Party B’s salary is RMB 3.2 甲方应于每月号以货币或转帐形式足额支付乙方上述报酬。 Party A shall pay salary to Party B before the day of every month in the form of cash or bank-transfer. 3.3 乙方应遵守国家及地方的税法制度，自行缴纳其个人收入的个人所得税，甲方无义务为其代缴。 Party B shall pay personal income tax voluntarily according to the state’s tax law. Party A doesn’t shoulder the responsibility to withh old and remit taxes for Party B. 3.4 乙方在合同期内享受中国法律规定的节日，公休假日。 Party B is entitled with all legal holidays in accordance with the state’s regulations 四、雇佣合同的解除和终止

中英文对照合同11

采购合同 (Purchasing Contract) 合同编号(Contract NO.)： 合同签订地点(Signed At)：东营 签订时间(Date)：年月日出卖人(Seller)： 买受人(Buyer)： 鉴于：根据【中华人民共和国合同法】及相关法律法规，本着平等自愿、等价有偿、诚实诚信的原则，经双方协商一致，订立本合同。 According to the Contract law of the People's Republic of China and relevant laws and regulations,we conclude the contract on the basis of equality, voluntariness,compensation of equal value and sincerity. 第一条标的、数量、价款及交（提）货时间 Item 1 (object)Quantity Price and Delivery time 物资编码名称及规格型号Commodity code and type 生产厂家 Manufacture r 计量单位 Unit 数量 Quantity 单价（元） Unit Price 总金额（元） Total Amount 备注 Note 不含税总金额（人民币） Total Amount (V AT excluded) 交提货时间、数量：年月日至年月日全部交货。 Delivery time: From to 第二条质量标准：标准代号、编号和标准名称：GB150-98. Item 2 Quality standard: standard code,serial number and standard name:GB150-98. 第三条出卖人对质量负责的条件及期限 Item 3 Conditions and time limits that Sellers shall be held responsibility for 1. 质量负责条件和期限按正常运行12个月止执行。 1. Quality responsible conditions and time limits shall not be valid until the product has been functioning properly for 12 months 2. 出卖人对标的物的质量负责，产品均附质检报告单，质量保证书。如果出卖人知道或 者应当知道所处卖产品存在质量缺陷，所承担的质量保证期限不受前款质量负责期限的约束，应依法承担相应责任。 2. Sellers shall be responsible for the quality of the marks.The products should include the Quality Inspection Report and Quality Guarantee.If the sellers know or should know the products they sell with defects in quality,the quality assurance time limits should not be subject to the previous quality responsibility deadline and they should be held due responsibility for it. 第四条包装标准：标准包装，产品所需包装由出卖人合理包装，适合水运和长途内陆运输，防潮，防湿，防锈，防震。 Item 4 Packaging standard: Standard packaging, the sellers should package the products properly, it should be suitable for shipment and long distance inland transportation. The packaging of the products should be resistant of dampness, moisture, rust and shock. 第五条随机的必备品、配件、技术资料、工具数量及供应方法：随设备交货一起交齐。 Item 5 The accompanied necessary materia l, accessories, technical information ,quantity of

国际贸易合同协议书样本中英文对照

国际贸易合同协议书样本中英文对照 文件编号TT-00-PPS-GGB-USP-UYY-0089

CONTRACT NO.: DATE: THE BUYERS: ADDRESS : TEL: FAX: THE SELLERS: ADDRESS: TEL: FAX: This Contract is made by and between the Buyers and the Sellers, whereby the Buyers agree to buy and the Sellers agree to sell the under mentioned commodity according to the terms and conditions stipulated below: 买方与卖方就以下条款达成协议： 1. COMMODITY: 2. COUNTRY AND MANUFACTURERS: 原产国及造商： 3. PACKING: To be packed in standard airway packing. The Sellers shall be liable for any damage of the commodity and expenses incurred on account of improper packing and for any rust attributable to inadequate or improper protective measures taken by the sellers in regard to the